CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
TRANSPORT SERVICES Upon the conclusion of such multilateral negotiations, the Parties shall conduct a review for the purpose of discussing appropriate amendments to this Agreement so as to incorporate the results of such multilateral negotiations.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Management of Special and Technical Environment Each certificated support person demonstrates an acceptable level of performance in managing and organizing the special materials, equipment and environment essential to the specialized programs.
Environmental, Health and Safety Matters (a) Comply in all material respects with all applicable Environmental Laws, including, without limitation, obtaining and complying with and maintaining any and all licenses, approvals, notifications, registrations or permits required by applicable Environmental Laws. For purposes of this Section 5.12(a), material noncompliance by the Company, any of its Subsidiaries or any tenant or subtenant, with any applicable Environmental Law shall be deemed not to constitute a breach of this covenant provided that, upon learning of any actual or suspected material noncompliance, the Company and the relevant Subsidiaries shall promptly undertake all reasonable efforts to achieve material compliance (or contest in good faith by appropriate proceedings the alleged violation or applicable Environmental Law at issue and (to the extent required by GAAP) provide on the books of the Company or any of its Subsidiaries, as the case may be, reserves in accordance with GAAP with respect thereto), and provided further that, in any case, such noncompliance, and any other noncompliance with applicable Environmental Law, individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect. (b) Promptly comply in all material respects with all lawful orders and directives of all Governmental Authorities regarding applicable Environmental Laws, except to the extent that the validity thereof is currently being contested in good faith by appropriate proceedings and (to the extent required by GAAP) reserves in accordance with GAAP with respect thereto have been provided on the books of the Company or any of its Subsidiaries, as the case may be. (c) Defend, indemnify and hold harmless the Administrative Agent and the Lenders, and their respective parents, subsidiaries, affiliates, employees, agents, officers and directors, from and against any claims, demands, penalties, fines, liabilities, settlements, damages, costs and expenses of whatever kind or nature, known or unknown, contingent or otherwise, arising out of, or in any way relating to the violation of, noncompliance with or liability under any Environmental Laws applicable to the Company or any of its Subsidiaries or any of their respective operations or properties, or any orders, requirements or demands of Governmental Authorities related thereto, including, without limitation, attorney’s and consultant’s fees, investigation and laboratory fees, response costs, court costs and litigation expenses, except to the extent that any of the foregoing arise out of the gross negligence or willful misconduct of (or, as determined pursuant to a claim initiated by the Company, breach in bad faith of its express obligations under the applicable Loan Documents by) the party seeking indemnification therefor, in each case, as determined by a final non-appealable judgment by a court of competent jurisdiction. This indemnity shall continue in full force and effect regardless of the termination of this Agreement.
Technical Safeguards 1. USAC and DSS will process the data matched and any data created by the match under the immediate supervision and control of authorized personnel to protect the confidentiality of the data, so unauthorized persons cannot retrieve any data by computer, remote terminal, or other means. 2. USAC and DSS will strictly limit authorization to these electronic data areas necessary for the authorized user to perform their official duties. All data in transit will be encrypted using algorithms that meet the requirements of the Federal Information Processing Standard (FIPS) Publication 140-2 or 140-3 (when applicable). 3. Authorized system users will be identified by User ID and password, and individually tracked to safeguard against the unauthorized access and use of the system. System logs of all user actions will be saved, tracked and monitored periodically. 4. USAC will transmit data to DSS via encrypted secure file delivery system. For each request, a response will be sent back to USAC to indicate success or failure of transmission.
Contract Work Hours and Safety Standards Act The following clauses apply to any Federal-aid construction contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses shall be inserted in addition to the clauses required by 29 CFR 5.5(a) or 29 CFR 4.6. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.
Procedural and Operational Requirements By accepting and using the Financial Assistance awarded under this Agreement and for this Program Element, LPHA agrees to conduct the following activities in accordance with the indicated procedural and operational requirements: a. LPHA must operate its Communicable Disease program in accordance with the Requirements and Standards for the Control of Communicable Disease set forth in ORS Chapters 431, 432, 433 and 437 and OAR Chapter 333, Divisions 12, 17, 18, 19 and 24, as such statutes and rules may be amended from time to time. b. LPHA must use all reasonable means to investigate in a timely manner all reports of Reportable Diseases, infections, or conditions. To identify possible sources of infection and to carry out appropriate control measures, the LPHA Administrator shall investigate each report following procedures outlined in OHA’s Investigative Guidelines or other procedures approved by OHA. OHA may provide assistance in these investigations, in accordance with OAR 333-019-0000. Investigative guidelines are available at: xxxx://xxx.xxxxxx.xxx/oha/PH/DiseasesConditions/CommunicableDisease/ReportingCommuni cableDisease/ReportingGuidelines/Pages/index.aspx c. As part of its Communicable Disease control program, LPHA must, within its service area, investigate the Outbreaks of Communicable Diseases, institute appropriate Communicable Disease control measures, and submit required information in a timely manner regarding the Outbreak to OHA in Orpheus (or Opera for COVID-19 Cases and XXXXX for COVID-19 contacts) as prescribed in OHA CD Investigative Guidelines available at: d. LPHA must establish and maintain a single telephone number whereby physicians, hospitals, other health care providers, OHA and the public can report Communicable Diseases and Outbreaks to LPHA 24 hours a day, 365 days a year. LPHA may employ an answering service or 911 system, but the ten-digit number must be available to callers from outside the local emergency dispatch area, and LPHA must respond to and investigate reported Communicable Diseases and Outbreaks. e. LPHA must attend Communicable Disease 101 and Communicable Disease 303 training. f. LPHA must attend monthly Orpheus user group meetings or monthly Orpheus training webinars.
