Transport Fee for Delivered Cargoes Sample Clauses

Transport Fee for Delivered Cargoes. 11.1.1 In consideration of the Services provided by the Transporter, Project Co shall pay to the Transporter the Transport Fee, calculated in accordance with Clause 11.1.2 in respect of each Delivered Cargo that is not a Swapped Cargo. 11.1.2 The "Transport Fee" in respect of each Delivered Cargo (excluding any Swapped Cargoes) shall be calculated as follows: Transport Fee = [DES CSP x Discharge Volume] – [FOB CSP x Loaded Volume] Where: Discharge Volume = the volume of LNG (in MMBtu) in the Delivered Cargo that is delivered to DES Buyer, as measured at the Delivery Point; Loaded Volume = the volume of LNG (in MMBtu) in the Loaded Cargo that is loaded from the Production Facility, as measured at the Loading Point; DES CSP = the “CSP” calculated in accordance with Section 9.1.1 and Section 9.1.2 of the DES SPA; DES X0 = “X0” as defined in the DES SPA; DES Xy = “Xy” as defined in the DES SPA; FOB CSP = (1.15 x HHFOB) + FOB Xy; FOB X0 = *** x DES X0; and FOB Xy = [*** + (*** x DES Xy / DES X0)] x FOB X0.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Transport Fee for Delivered Cargoes. 11.1.1 In consideration of the Services provided by the Transporter, Project Co shall pay to the Transporter the Transport Fee, calculated in accordance with Clause 11.1.2 in respect of each Delivered Cargo that is not a Swapped Cargo.
Sample 1
Transport Fee for Delivered Cargoes. 11.1.1 In consideration of the Services provided by the Transporter, Project Co shall pay to the Transporter the Transport Fee, calculated in accordance with Clause 11.1.2 in respect of each Delivered Cargo that is not a Swapped Cargo. 11.1.2 The "Transport Fee" in respect of each Delivered Cargo (excluding any Swapped Cargoes) shall be calculated as follows: Transport Fee = [DES CSP x Discharge Volume] – [FOB CSP x Loaded Volume] Where: Discharge Volume = the volume of LNG (in MMBtu) in the Delivered Cargo that is delivered to DES Buyer, as measured at the Delivery Point; Loaded Volume = the volume of LNG (in MMBtu) in the Loaded Cargo that is loaded from the Production Facility, as measured at the Loading Point; DES CSP = either, CSP1 or CSP2, determined as follows: (i) subject to sub-part (3) of item (ii) below, where the relevant cargo hereunder is or corresponds to a T1Q Cargo under the DES SPA that is scheduled for delivery before the Conversion Date, DES CSP shall be “CSP1” (as defined in and calculated in accordance with the DES SPA); and (ii) where the relevant cargo hereunder is or corresponds to: (1) a T2Q Cargo under the DES SPA, (2) a T1Q Cargo under the DES SPA that is scheduled for delivery on or after the Conversion Date or (3) a T1Q Cargo under the DES SPA that is scheduled for delivery before the Conversion Date but in respect of which “CSP2” applies in accordance with Section 7.1.3(b) of the DES SPA, DES CSP shall be “CSP2” (as defined in and calculated in accordance with the DES SPA); DES X0 = “X0” as defined in the DES SPA; DES Xy = “Xy” as defined in the DES SPA; FOB CSP = (1.15 x HHFOB) + FOB Xy; FOB X0 = (i) in respect of CSP1, FOB X0 = *** x DES X0; and (ii) in respect of CSP2, FOB X0 = *** x DES X0; FOB Xy = (i) in respect of CSP1, FOB Xy = [*** + (*** x DES Xy / DES X0)] x FOB X0; and (ii) in respect of CSP2, FOB Xy = [*** + (*** x DES Xy / DES X0)] x FOB X0.
Sample 1

Related to Transport Fee for Delivered Cargoes

  • Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • TRANSPORT SERVICES Upon the conclusion of such multilateral negotiations, the Parties shall conduct a review for the purpose of discussing appropriate amendments to this Agreement so as to incorporate the results of such multilateral negotiations.

  • Delivery Point The delivery point is the point of delivery of the Power Product to the CAISO Controlled Grid (the “Delivery Point”). Seller shall provide and convey to Buyer the Power Product from the Generating Facility at the Delivery Point. Title to and risk of loss related to the Power Product transfer from Seller to Buyer at the Delivery Point.

  • Delivery Points ‌ Project water made available to the Agency pursuant to Article 6 shall be delivered to the Agency by the State at the delivery structures established in accordance with Article 10.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Transportation Charges The cost of transporting Employees and Material necessary for the Mining Operations.

  • DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.

  • Unbundled Voice Loops (UVLs) 2.2.1 BellSouth shall make available the following UVLs:

  • How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!