Adverse Weather Shall be only weather that satisfies all of the following conditions: (1) unusually severe precipitation, sleet, snow, hail, or extreme temperature or air conditions in excess of the norm for the location and time of year it occurred based on the closest weather station data averaged over the past five years, (2) that is unanticipated and would cause unsafe work conditions and/or is unsuitable for scheduled work that should not be performed during inclement weather (i.e., exterior finishes), and (3) at the Project.
Students with Disabilities The Charter School shall comply with all federal special education laws and regulations, including Section 504 of the Rehabilitation Act of 1973, Title II of the Americans with Disabilities Act, and the Individuals with Disabilities Education Act.
Reasonable Accommodation for Applicants / Employees with Disabilities The contractor must be familiar
Organ Transplants This plan covers organ and tissue transplants when ordered by a physician, is medically necessary, and is not an experimental or investigational procedure. Examples of covered transplant services include but are not limited to: heart, heart-lung, lung, liver, small intestine, pancreas, kidney, cornea, small bowel, and bone marrow. Allogenic bone marrow transplant covered healthcare services include medical and surgical services for the matching participant donor and the recipient. However, Human Leukocyte Antigen testing is covered as indicated in the Summary of Medical Benefits. For details see Human Leukocyte Antigen Testing section. This plan covers high dose chemotherapy and radiation services related to autologous bone marrow transplantation to the extent required under R.I. Law § 27-20-60. See Experimental or Investigational Services in Section 3 for additional information. To speak to a representative in our Case Management Department please call 1-401- 000-0000 or 1-888-727-2300 ext. 2273. The national transplant network program is called the Blue Distinction Centers for Transplants. SM For more information about the Blue Distinction Centers for TransplantsSM call our Customer Service Department or visit our website. When the recipient is a covered member under this plan, the following services are also covered: • obtaining donated organs (including removal from a cadaver); • donor medical and surgical expenses related to obtaining the organ that are integral to the harvesting or directly related to the donation and limited to treatment occurring during the same stay as the harvesting and treatment received during standard post- operative care; and • transportation of the organ from donor to the recipient. The amount you pay for transplant services, for the recipient and eligible donor, is based on the type of service.
Critical Illness Three (3) days per year, with pay, shall be granted in the case of a critical illness or accident to a member of the employee's immediate family as defined in Section 9.4.2. A statement by the physician verifying the need for the employee to be present with the immediate family member shall be attached to the absence form.
FLORIDA CONVICTED/SUSPENDED/DISCRIMINATORY COMPLAINTS By submission of an offer, the respondent affirms that it is not currently listed in the Florida Department of Management Services Convicted/Suspended/Discriminatory Complaint Vendor List.
Normal Commercial Relations Anything contained in this Indenture to the contrary notwithstanding, the Loan Trustee, any Noteholder or any other party to any of the Operative Documents or the Pass Through Documents or any of their affiliates may conduct any banking or other financial transactions, and have banking or other commercial relationships, with the Company, fully to the same extent as if this Indenture were not in effect, including without limitation the making of loans or other extensions of credit to the Company for any purpose whatsoever, whether related to any of the transactions contemplated hereby or otherwise.
Proof of Illness An Employee may be required to produce a certificate from a medical practitioner for any illness in excess of three (3) consecutive working days, certifying that he/she is unable to carry out his/her duties due to illness. In addition, the Employer may require such certificate for absence for less than three (3) days where the Employee has been warned of excessive absenteeism.
Illness injury, or pregnancy-related condition of a member of the employee’s immediate family where the employee’s presence is reasonably necessary for the health and welfare of the employee or affected family member;
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
