Unit 5 Scrubber Tie-In Sample Clauses

Unit 5 Scrubber Tie-In. Contractor shall perform Unit 5 Scrubber Tie-In in accordance with the Guaranteed Tie-In Commencement Date and Guaranteed Tie-In Completion Date, both as may be adjusted in accordance with Exhibit I. Owner shall have the right to make adjustments to such outage schedule, including delaying or accelerating the Guaranteed Tie-In Commencement Date or the Guaranteed Tie-In Completion Date; provided, that as a result of any such adjustment, Contractor shall be entitled to an equitable adjustment in the Contract Price and the Schedule in accordance with Article 8. *** (or longer if Contractor is entitled to a Change upon inspection of the tie-in ducts which reveals differing conditions) to such portion of the Site as Contractor may reasonably require to perform the Work during the outage for Unit 5 Scrubber Tie-In.
Sample 1Sample 2
AutoNDA by SimpleDocs
Unit 5 Scrubber Tie-In. Contractor shall perform Unit 5 Scrubber Tie-In in accordance with the Guaranteed Unit 5 Tie-In Commencement Date and Guaranteed Unit 5 Tie-In Completion Date, both as may be adjusted pursuant to a Change Order. Owner shall have the right to make adjustments to such outage schedule, including delaying or accelerating the Guaranteed Unit 5 Tie-In Commencement Date or the Guaranteed Unit 5 Tie-In Completion Date; provided, that as a result of any such adjustment, Contractor shall be entitled to an equitable adjustment in the Contract Price and the Schedule in accordance with Article 8. *** to such portion of the Site as Contractor may reasonably require to perform the following Work during the outage for the Unit 5 Scrubber Tie-In: (1) removal of blanking plates and (2) activation of the previously installed *** quick acting relief dampers, as set forth in more detail in Exhibit A.
Sample 1

Related to Unit 5 Scrubber Tie-In

  • XXXREAS the Trust is registered under the Investment Company Act of 1940, as amended, (the "1940 Act") as an open-end, series management investment company; and

  • Project Scope This section should contain SOW summary information including: o Project definition and expected duration o Project goals, objectives, o Priorities & expectations o Project approach & responsibilities o Overall coordination and assumptions

  • Commissioning preparation of a system or systems to allow hydrocarbons or other process fluids to be safely introduced into the system or systems for processing. In this phase testing will focus on systems, including utilities.

  • Project Schedule Contractor shall perform the Work in accordance with the Project Schedule.

  • Tax Periods Beginning Before and Ending After the Closing Date The Company or the Purchaser shall prepare or cause to be prepared and file or cause to be filed any Returns of the Company for Tax periods that begin before the Closing Date and end after the Closing Date. To the extent such Taxes are not fully reserved for in the Company’s financial statements, the Sellers shall pay to the Company an amount equal to the unreserved portion of such Taxes that relates to the portion of the Tax period ending on the Closing Date. Such payment, if any, shall be paid by the Sellers within fifteen (15) days after receipt of written notice from the Company or the Purchaser that such Taxes were paid by the Company or the Purchaser for a period beginning prior to the Closing Date. For purposes of this Section, in the case of any Taxes that are imposed on a periodic basis and are payable for a Taxable period that includes (but does not end on) the Closing Date, the portion of such Tax that relates to the portion of such Tax period ending on the Closing Date shall (i) in the case of any Taxes other than Taxes based upon or related to income or receipts, be deemed to be the amount of such Tax for the entire Tax period multiplied by a fraction the numerator of which is the number of days in the Tax period ending on the Closing Date and the denominator of which is the number of days in the entire Tax period (the “Pro Rata Amount”), and (ii) in the case of any Tax based upon or related to income or receipts, be deemed equal to the amount that would be payable if the relevant Tax period ended on the Closing Date. The Sellers shall pay to the Company with the payment of any taxes due hereunder, the Sellers’ Pro Rata Amount of the costs and expenses incurred by the Purchaser or the Company in the preparation and filing of the Tax Returns. Any net operating losses or credits relating to a Tax period that begins before and ends after the Closing Date shall be taken into account as though the relevant Tax period ended on the Closing Date. All determinations necessary to give effect to the foregoing allocations shall be made in a reasonable manner as agreed to by the parties.

  • Production Work Except as agreed to in writing by the Parties pursuant to the "Production Work" section of the Standard Online Commerce Terms & Conditions attached hereto as Exhibit F, MP will be responsible for all production work associated with the Affiliated MP Site, including all related costs and expenses.

  • ADJUSTMENT OF THE DISTRIBUTOR’S ALLOCABLE PORTION AND EACH SUCCESSOR DISTRIBUTOR’S ALLOCABLE PORTION The parties to the Distribution Agreement recognize that, if the terms of any distributor’s contract, any distribution plan, any prospectus, the FINRA Conduct Rules or any other applicable law change so as to disproportionately reduce, in a manner inconsistent with the intent of this Distribution Agreement, the amount of the Distributor’s Allocable Portion or any Successor Distributor’s Allocable Portion had no such change occurred, the definitions of the Distributor’s Allocable Portion and/or the Successor Distributor’s Allocable Portion in respect of the Class C shares relating to a Fund shall be adjusted by agreement among the relevant parties; provided, however, if the Distributor, the Successor Distributor and the Fund cannot agree within thirty (30) days after the date of any such change in applicable laws or in any distributor’s contract, distribution plan, prospectus or the FINRA Conduct Rules, they shall submit the question to arbitration in accordance with the commercial arbitration rules of the American Arbitration Association and the decision reached by the arbitrator shall be final and binding on each of them. SCHEDULE B to the Amended and Restated Principal Underwriting Agreement ALLOCATION SCHEDULE The following relates solely to Class 529-C shares. The Distributor’s Allocable Portion of Distribution Fees and CDSCs in respect of Class 529-C shares shall be 100% until such time as the Distributor shall cease to serve as exclusive distributor of Class 529-C shares; thereafter, collections that constitute CDSCs and Distribution Fees relating to Class 529-C shares shall be allocated among the Distributor and any successor distributor (“Successor Distributor”) in accordance with this Schedule. At such time as the Distributor’s Allocable Portion of the Distribution Fees equals zero, the Successor Distributor shall become the Distributor for purposes of this Allocation Schedule. Defined terms used in this Schedule and not otherwise defined herein shall have the meanings assigned to them in the Principal Underwriting Agreement (the “Distribution Agreement”), of which this Schedule is a part. As used herein the following terms shall have the meanings indicated:

  • DTC DIRECT REGISTRATION SYSTEM AND PROFILE MODIFICATION SYSTEM (a) Notwithstanding the provisions of Section 2.4 of the Deposit Agreement, the parties acknowledge that DTC’s Direct Registration System (“DRS”) and Profile Modification System (“Profile”) apply to the American Depositary Shares upon acceptance thereof to DRS by DTC. DRS is the system administered by DTC that facilitates interchange between registered holding of uncertificated securities and holding of security entitlements in those securities through DTC and a DTC participant. Profile is a required feature of DRS that allows a DTC participant, claiming to act on behalf of an Owner of American Depositary Shares, to direct the Depositary to register a transfer of those American Depositary Shares to DTC or its nominee and to deliver those American Depositary Shares to the DTC account of that DTC participant without receipt by the Depositary of prior authorization from the Owner to register that transfer.

  • Development Plan As defined in Section 3.2(a).

  • Construction Phase During Construction, DESIGN/BUILDER shall provide Engineering and Design Professional Services as necessary to complete the Project.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!