Uncovering and Making Openings Sample Clauses

Uncovering and Making Openings. The Contractor shall uncover any part of the Works or make openings in or through the same as the Engineer may from time to time instruct and shall reinstate and make good such part. If any such part has been covered up or put out of view after compliance with the requirement of Sub-Clause 7.11 and is found to be executed in accordance with the Contract, the Engineer shall, after due consultation with the Employer and the Contractor, determine the amount of the Contractor’s costs in respect of such uncovering, making openings in or through, reinstating and making good the same, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. In any other case all costs shall be borne by the Contractor.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Uncovering and Making Openings. The Contractor shall uncover any part of the Works or make openings in or through the same as LOST may instruct, and shall reinstate and make good such part. If any such part has been covered up or put out of view after compliance with the requirement of the clause above and is found to be executed in accordance with the Contract, LOST shall determine the amount of the Contractor's costs in respect of such uncovering, making openings in or through, reinstating and making good the same, which shall be added to the Contract Price, and shall notify the Contractor accordingly. In any other case all costs shall be borne by the Contractor.
Sample 1Sample 2Sample 3See All (7)
Uncovering and Making Openings. The Contractor shall uncover any part or parts of the works or make openings in or through the same as the Engineer may from time to time direct and shall reinstate and make good such part or parts to the satisfaction of the Engineer. If any such part or parts have been covered up or put out of view after compliance with the requirement of sub-clause (1) of this clause and are found to be executed in accordance with the Contract, the expenses of uncovering, making openings in or through, reinstating and making good the same shall be borne by GMDC, but in any other case all cost shall be borne by the Contractor.
Sample 1Sample 2Sample 3See All (5)
Uncovering and Making Openings. (a) The Contractor shall uncover any part of the Works or make openings in or through the same as the Superintending Officer may from time to time instruct and shall reinstate and make good such part of the Works to the satisfaction of the Superintending Officer. (b) If any such part of the Works has been covered up or put out of view after compliance with the requirements of sub-clauses 15.5(a) and 15.5(b) and is found to be executed in accordance with the Contract then, such work carried out by the Contractor shall be deemed a Variation.
Sample 1Sample 2Sample 3
Uncovering and Making Openings. Defects during the Progress of the Works
Sample 1Sample 2Sample 3
Uncovering and Making Openings. If, following discovery of defective workmanship or materials in any part of the Work, Owner has reasonable grounds to suspect that further parts of the Work may be similarly defective, Contractor shall, upon the reasonable request of Owner, provide Owner clear evidence that such other parts are not defective to the reasonable satisfaction of Owner or shall uncover such further parts of the Work or make further openings, in or through the same, and Contractor shall inspect and repair, if necessary, any such parts. The costs of such work carried out by Contractor under this Section shall be borne by Contractor, unless the parts of the Work so uncovered turn out to be not defective in which case Owner shall bear all such costs.
Sample 1Sample 2
Uncovering and Making Openings. The Contractor shall uncover any part or parts of the Works or make openings in or through the same as the Superintending Officer may from time to time instruct in writing and shall reinstate and make good such part or parts to the satisfaction of the Superintending Officer. If any such part or parts have been covered up or put out of view after compliance with the requirements of Clause 10.5 and are found to be executed in accordance with the Contract, then subject to compliance by the Contractor with Clauses 14, 23 and 32, the Superintending Officer may grant an extension of time pursuant to Clause 14.2, and may certify pursuant to Clause 32 such sum as may be reasonable to cover the costs of uncovering, making openings in or through, reinstating and making good the same and any Loss and Expenses shall be borne by the Contractor and the Contractor shall also not be entitled to any extension of time for any delay caused by such instruction.
Sample 1
AutoNDA by SimpleDocs
Uncovering and Making Openings. If, following discovery of defective workmanship or materials in any part of the Work, Owner has reasonable grounds to suspect that further parts of the Work may be similarly defective, Contractor shall, upon the reasonable request of Owner, provide Owner clear evidence that such other parts are not defective to the reasonable satisfaction of Owner or shall uncover such further parts of the Work or make further openings, in or through the same, and Contractor shall inspect and repair, if necessary, any such parts. Unless the cause of such defective workmanship is shown to be the result of Gross Negligence or willful misconduct, the costs of such work carried out by Contractor under this Section shall be added to the Craft Labor Costs and shall be applied against the existing Cost Target — Craft Labor without a Change. If the cause of such defective workmanship is shown to be the result of Gross Negligence or willful misconduct of Contractor, Contractor shall bear the full costs of repair.
Sample 1

Related to Uncovering and Making Openings

  • Skidding and Yarding Methods of skid- ding or yarding specified for particular areas, if any, are indicated on Sale Area Map. Outside Clearcutting Units and construction clearings, insofar as ground conditions permit, products shall not be skidded against reserve trees or groups of reproduction and tractors shall be equipped with a winch to facilitate skidding. B6.421 Rigging. Insofar as practicable, needed rigging shall be slung on stumps or trees desig- nated for cutting.

  • Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor. 12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.

  • Weighing and Scaling Costs Purchaser agrees to pay for all weighing costs for logs delivered regardless if logs are purchased on a weight or scale basis. In addition, Purchaser agrees to pay for all scaling costs for logs delivered on a scale basis. Purchaser also agrees to pay for all costs associated with the transmission and reporting of scale or weight data.

  • CUTTING AND PATCHING The Contractor shall be responsible for cutting, fitting or patching required to complete the Work or to make its parts fit together properly.

  • Aggravating and Mitigating Factors The penalties in this matter were determined in consideration of all relevant circumstances, including statutory factors as described in CARB’s Enforcement Policy. CARB considered whether the violator came into compliance quickly and cooperated with the investigation; the extent of harm to public health, safety and welfare; nature and persistence of the violation, including the magnitude of the excess emissions; compliance history; preventative efforts taken; innovative nature and the magnitude of the effort required to comply, and the accuracy, reproducibility, and repeatability of the available test methods; efforts to attain, or provide for, compliance prior to violation; action taken to mitigate the violation; financial burden to the violator; and voluntary disclosure. The penalties are set at levels sufficient to deter violations, to remove any economic benefit or unfair advantage from noncompliance, to obtain swift compliance, and the potential costs, risks, and uncertainty associated with litigation. Penalties in future cases might be smaller or larger depending on the unique circumstances of the case.

  • Ordering and Maintenance CBB shall use Verizon’s electronic Operations Support System access platforms to submit Orders and requests for maintenance and repair of Services, and to engage in other pre-ordering, ordering, provisioning, maintenance and repair transactions. If Verizon has not yet deployed an electronic capability for CBB to perform a pre-ordering, ordering, provisioning, maintenance or repair, transaction offered by Verizon, CBB shall use such other processes as Verizon has made available for performing such transaction (including, but not limited, to submission of Orders by telephonic facsimile transmission and placing trouble reports by voice telephone transmission).

  • Sealing and Marking of Bids The bidder shall seal the original and each copy of the bid in separate envelopes duly marking the envelopes “ORIGINAL” and “COPY”. The envelopes shall then be sealed in an outer separate envelope.

  • Felling and Bucking Felling shall be done to minimize breakage of Included Timber and dam- age to residual timber. Unless agreed otherwise, felling shall be done by saws or shears. Bucking shall be done to permit removal of all minimum pieces set forth in A2. B6.411 Felling in Clearings. Insofar as ground conditions, tree lean, and shape of clearings per- mit, trees shall be felled so that their tops do not extend outside Clearcutting Units, construction clearings, and ar- eas of regeneration cutting. B6.000 Xxxxx Xxxxxxx. Stumps shall not exceed, on the side adjacent to the highest ground, the maximum heights set forth in A6, except that occasional stumps of greater heights are acceptable when Purchaser determines that they are necessary for safe and efficient conduct of logging. Unless otherwise agreed, Purchaser shall re-cut high stumps so they will not exceed heights specified in A6 and shall dispose of severed portions in the same manner as other logging debris. The xxxxx heights shown in A6 were selected with the objective of maximum reasonable utilization of the timber, unless Sale Area Map shows special areas where xxxxx heights are lower for aesthetic, land treatment, or silvicultural rea- sons.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

  • Training and Orientation (a) No employee shall be required to work on any job or operate any piece of equipment until he/she has received proper training and instruction. (b) The Employer shall provide sufficient and adequate training and/or orientation to any employee working in a new or unfamiliar work area or position.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!