Valuation Completion Date Sample Clauses

Valuation Completion Date. The Trading Day, during the period commencing on and including the 31st Trading Day following the Hedging Completion Date and ending on and including the Expiration Date, specified as such by the Seller, in its sole judgment, by delivering a notice designating such Trading Day as a Valuation Completion Date by the close of business on the Business Day immediately following such Trading Day; provided that if the Seller fails to validly designate the Valuation Completion Date prior to the Expiration Date, the Valuation Completion Date shall be the Expiration Date.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Valuation Completion Date. The Trading Day, during the period commencing on and including the [***] Trading Day following the Valuation Commencement Date and ending on and including the Expiration Date, specified as such by the Seller, in its sole judgment, by delivering a notice designating such Trading Day as a Valuation Completion Date by the end of such Trading Day; provided that if the Seller fails to validly designate the Valuation Completion Date prior to the Expiration Date, the Valuation Completion Date shall be the Expiration Date. 5 Section 9.02: Not Applicable EXHIBIT A [Letterhead of Purchaser] JPMorgan Chase Bank, National Association c/o X.X. Xxxxxx Securities Inc. 000 Xxxx Xxxxxx 11th Floor New York, New York 10172 Re: Accelerated Purchase of Equity Securities Ladies and Gentlemen: In connection with our entry into the Confirmation dated as of February 8, 2008 (the “Confirmation”), we hereby represent that set forth below is the total number of shares of our common stock purchased by or for us or any of our affiliated purchasers in Rule 10b-18 purchases of blocks (all defined in Rule 10b-18 under the Securities Exchange Act of 1934) pursuant to the once-a-week block exception set forth in Rule 10b-18(b)(4) during the four full calendar weeks immediately preceding the first day of the [Hedging Period] [Seller Termination Share Purchase Period] (as defined in the Confirmation) and the week during which the first day of the [Hedging Period] [Seller Termination Share Purchase Period] occurs.
Sample 1
Valuation Completion Date. The Trading Day, during the period commencing on and including the 87th Trading Day following the Hedging Completion Date and ending on and including the Expiration Date, specified as such by the Seller, in its sole judgment, by delivering a notice designating such Trading Day as a Valuation Completion Date by the close of business on the Business Day immediately following such Trading Day; provided that if the Seller fails to validly designate the Valuation Completion Date prior to the Expiration Date, the Valuation Completion Date shall be the Expiration Date. EXHIBIT A FORM OF HEDGING COMPLETION NOTICE JPMorgan Chase Bank, National Association c/o X.X. Xxxxxx Securities LLC 000 Xxxx Xxxxxx, 00xx Xxxxx Xxx Xxxx, Xxx Xxxx 00000 [Date] Covance Inc. 000 Xxxxxxxx Xxxxxx Xxxxxxxxx, Xxx Xxxxxx 00000 Ladies and Gentlemen: This letter is a hedging completion notice within the meaning of Section 2.04(c) of the Confirmation dated as of November 8, 2010 (the “Confirmation”) between Covance Inc. (the “Purchaser”) and JPMorgan Chase Bank, National Association, London Branch (the “Seller”), by X.X. Xxxxxx Securities LLC, as its agent. Capitalized terms used herein have the meanings set forth in the Confirmation. This hedging completion notice relates to the Transaction described in the Confirmation. Upon the terms and subject to the conditions of the Confirmation, the terms of the Transaction shall be as follows:
Sample 1

Related to Valuation Completion Date

  • Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.

  • Final Completion The full and final completion of all Work in accordance with the Contract Documents.

  • Project Completion Part 1 – Material Completion

  • VALUATION PERIOD Each Division will be valued at the end of each Valuation Period on a Valuation Date. A Valuation Period is each Business Day together with any non-Business Days before it. A Business Day is any day the New York Stock Exchange (NYSE) is open for trading, and the SEC requires mutual funds, unit investment trusts, or other investment portfolios to value their securities. ACCUMULATION VALUE The Accumulation Value of this Contract is the sum of the amounts in each of the Divisions of the Variable Separate Account and General Account. You select the Divisions of the Variable Separate Account and General Account to which to allocate the Accumulation Value. The maximum number of Divisions to which the Accumulation Value may be allocated at any one time is shown in the Schedule. ACCUMULATION VALUE IN EACH DIVISION ON THE CONTRACT DATE On the Contract Date, the Accumulation Value is allocated to each Division as elected by you, subject to certain terms and conditions imposed by us. We reserve the right to allocate premium to the Specially Designated Division during any Right to Examine contract period. After such time, allocation will be made proportionately in accordance with the initial allocation(s) as elected by you. ON EACH VALUATION DATE At the end of each subsequent Valuation Period, the amount of Accumulation Value in each Division will be calculated as follows:

  • Valuation Time At the close of trading of the regular trading session on the Exchange; provided that if the principal trading session is extended, the Calculation Agent shall determine the Valuation Time in its reasonable discretion.

  • Following Completion (A) the Parties shall use all reasonable endeavours to procure that, and to procure that the members of their respective Groups use all reasonable endeavours to procure that, any necessary third party execute such documents and do such acts and things as may be reasonably required for the purpose of giving to GSK and Haleon the full benefit of all relevant provisions of this Agreement; and

  • Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.

  • Evaluation Period Customer’s right to use the Services on a Trial Basis are time-limited and will terminate immediately upon the earlier of (i) the trial end date as specified in an Order Form or other document executed by the parties regarding such trial, or (ii) the start date of when Customer purchases a right to use such Services on a non-Trial Basis, or (iii) the date when QuoVadis terminates Customer’s right to use the Services on a Trial Basis (which QuoVadis may do at any time in its sole discretion). Customer must cease using the Services on a Trial Basis upon any such termination.

  • Substantial Completion “Substantial Completion” means the stage in the progress of the Work when the Work, or designated portions thereof, may still require minor modifications or adjustments but, in the Owner’s opinion, the Work has progressed to the point such that all parts of the Work under consideration are fully operational and usable for intended purposes, as evidenced by a Certificate of Substantial Completion approved by the Owner. If a Certificate of Occupancy is required by public authorities having jurisdiction over the Work, said certificate shall be issued before the Work or any portion thereof is considered substantially complete. When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor shall notify Owner’s Designated Representative (sometimes referred to as the “ODR”) and request a determination as to whether the Work or designated portion thereof is substantially complete. If the ODR does not consider the Work substantially complete, the ODR will notify the Contractor giving reasons therefore. Failure on the Owner’s part to list a reason does not alter the responsibility of the Contractor to complete all Work in accordance with the terms of this Agreement. After satisfactorily completing items identified by Owner’s Designated Representative, the Contractor shall then submit another request for the ODR to determine Substantial Completion. If The ODR considers the Work substantially complete, The ODR will prepare and deliver a certificate of Substantial Completion which shall establish the date of Substantial Completion, shall include a punch list of items to be completed or corrected before final completion and final payment, shall establish the time within which the Contractor shall finish the punch list, and shall establish responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work, warranty and insurance. Failure to include an item on the punch list does not alter the responsibility of the Contractor to complete all Work in accordance with the terms and conditions of this Agreement. The certificate of Substantial Completion shall be signed by the Owner and the Contractor to evidence acceptance of the responsibilities assigned to them in such certificate. Substantial Completion (as defined in this agreement) for all stages of the Work shall be achieved on or before the following Substantial Completion date: DATE FOR SUBSTANTIAL COMPLETION: TBD Under no circumstances will the time for Substantial Completion exceed this date without a written amendment to this Agreement. THE TIMES SET FORTH IN THE CONSTRUCTION DOCUMENTS ARE AN ESSENTIAL ELEMENT OF THE AGREEMENT. TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF THIS AGREEMENT.

  • Valuation Date The value of the Collateral shall be determined on the date of the Buy-In (or the payment made pursuant to Section 6.2 below).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!