Variation to Implementation Plan Sample Clauses

Variation to Implementation Plan. The Implementation Plan may be varied in accordance with the provisions of Clauses 4.3.1, 4.3.2 and 4.3.3 below: 4.3.1 The Implementation Plan may be varied by the written agreement of the parties. 4.3.2 If: 4.3.2.1 the Contractor is prevented or delayed from carrying out its obligations under this Contract in accordance with the Implementation Plan as a direct consequence of a failure by the Purchaser (or a third party supplier to the Purchaser) to perform a Purchaser Responsibility on or before the relevant date set out in the Implementation Plan (other than to the extent caused by a preceding breach of this Contract by the Contractor) (in this Clause 4.3 each a "Purchaser Delay Event"); and 4.3.2.2 the Contractor has promptly served a written notice on Purchaser setting out details of that Purchaser Delay Event and referring to this Clause 4.3, then:
Sample 1Sample 2
AutoNDA by SimpleDocs
Variation to Implementation Plan. The Implementation Plan may be varied in accordance with the provisions of Clauses 4.3.1, 4.3.2 and 4.3.3 below: 4.3.1 The Implementation Plan may be varied by the written agreement of the parties. 4.3.2 If: 4.3.2.1 the Contractor is prevented or delayed from carrying out its obligations under this Contract in accordance with the Implementation Plan as a direct consequence of a failure by the Purchaser (or a third party supplier to the Purchaser) to perform a Purchaser Responsibility on or before the relevant date set out in the Implementation Plan (other than to the extent caused by a preceding breach of this Contract by the Contractor) (in this Clause 4.3 each a "Purchaser Delay Event"); and 4.3.2.2 the Contractor has promptly served a written notice on Purchaser setting out details of that Purchaser Delay Event and referring to this Clause 4.3, then: 4.3.2.2.1 the Parties shall use all reasonable endeavours to mitigate the impact of such delay and to recover any resultant delay; and 4.3.2.2.2 the Parties shall agree (such agreement not to be unreasonably withheld or delayed by either Party) a reasonable extension of any subsequent dates set out in the Implementation Plan that are directly impacted by the Purchaser Delay Event, such extension having regard to the delay caused by the Purchaser Delay Event, the related dependencies set out in the Implementation Plan, and the consequences of any delay upon Purchaser.
Sample 1
Variation to Implementation Plan. The Implementation Plan may be varied in accordance with the provisions of Clauses 4.3.1, 4.3.2 and 4.3.3 below: The Implementation Plan may be varied by the written agreement of the parties. If: the Contractor is prevented or delayed from carrying out its obligations under this Contract in accordance with the Implementation Plan as a direct consequence of a failure by the Purchaser (or a third party supplier to the Purchaser) to perform a Purchaser Responsibility on or before the relevant date set out in the Implementation Plan (other than to the extent caused by a preceding breach of this Contract by the Contractor) (in this Clause 4.3 each a "Purchaser Delay Event"); and the Contractor has promptly served a written notice on Purchaser setting out details of that Purchaser Delay Event and referring to this Clause 4.3, then: the Parties shall use all reasonable endeavours to mitigate the impact of such delay and to recover any resultant delay; and the Parties shall agree (such agreement not to be unreasonably withheld or delayed by either Party) a reasonable extension of any subsequent dates set out in the Implementation Plan that are directly impacted by the Purchaser Delay Event, such extension having regard to the delay caused by the Purchaser Delay Event, the related dependencies set out in the Implementation Plan, and the consequences of any delay upon Purchaser. If the Contractor is prevented or delayed from carrying out its obligations under the Contract in accordance with the Implementation Plan by reason of any event of Force Majeure then provided the Contractor has complied with the provisions of Clause 29 (Force Majeure) of the Conditions: the Parties shall use all reasonable endeavours to mitigate the impact of such delay and to recover any resultant delay; and the Parties shall agree (such agreement not to be unreasonably withheld or delayed by either Party) a reasonable extension of any subsequent dates set out in the Implementation Plan that are directly impacted by the event of Force Majeure, such extension having regard to the delay caused by the Force Majeure Event, the related dependencies set out in the Implementation Plan and the consequences of any delay upon Purchaser. In the event that the Parties cannot agree an amendment to the Implementation Plan pursuant to Clauses 4.3.2 or 4.3.3 then the provisions of Clause 39 (Dispute Resolution Procedure) of the Conditions shall apply. 5Implementation Environment Each party shall (as applic...
Sample 1

Related to Variation to Implementation Plan

  • Implementation Plan The Authority shall cause to be prepared an Implementation Plan meeting the requirements of Public Utilities Code Section 366.2 and any applicable Public Utilities Commission regulations as soon after the Effective Date as reasonably practicable. The Implementation Plan shall not be filed with the Public Utilities Commission until it is approved by the Board in the manner provided by Section 4.9.

  • Implementation of Agreement Each Party must promptly execute all documents and do all such acts and things as is necessary or desirable to implement and give full effect to the provisions of this Agreement.

  • Implementation of Corrective Action Plan After the Corrective Action Plan is finalized, the Purchasers shall use reasonable best efforts to implement the finalized Corrective Action Plan on the timeline set forth therein and provide periodic reports (as provided for therein) to the Sellers on the status of their implementation of the Corrective Action Plan.

  • Implementation of Changes If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for completion of Landlord’s Work, if any, and (ii) deposits with Landlord any Excess TI Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by Tenant of any estimate of the delay caused by such proposed Change, the TI Architect’s determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant.

  • Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.

  • COOPERATION IN IMPLEMENTATION On demand of the other Spouse and without undue delay or expense, each Spouse shall execute, acknowledge, or deliver any instrument, furnish any information, or perform any other acts reasonably necessary to carry out the provisions of this Agreement. If a Spouse fails to execute any document as required by this provision, the court may appoint the court clerk or his or her authorized designee to execute the document on that Xxxxxx’s behalf.

  • Implementation Report Within 150 days after the Effective Date, Ensign Group shall submit a written report to OIG summarizing the status of its implementation of the requirements of this CIA (Implementation Report). The Implementation Report shall, at a minimum, include: 1. the name, address, phone number, and position description of the Compliance Officer required by Section III.A, and a summary of other noncompliance job responsibilities the Compliance Officer may have; 2. the names and positions of the members of the Compliance Committee required by Section III.A; 3. the names and positions of the members of the Board of Directors who are responsible for satisfying the Board of Directors compliance obligations described in Section III.A.3; 4. a copy of Ensign Group’s Code of Conduct required by Section III.B.1; 5. the number of individuals required to complete the Code of Conduct certification required by Section III.B.1, the percentage of individuals who have completed such certification, and an explanation of any exceptions (the documentation supporting this information shall be available to OIG upon request); 6. a summary of all Policies and Procedures required by Section III.B (copies of the Policies and Procedures shall be made available to OIG upon request); 7. the following information regarding each type of training required by Section III.C: a. a description of such training, including a summary of the topics covered, the length of sessions, and a schedule of training sessions; b. the number of individuals required to be trained, percentage of individuals actually trained, and an explanation of any exceptions. A copy of all training materials and the documentation supporting this information shall be made available to OIG upon request. 8. a description of the Disclosure Program required by Section III.E; 9. the following information regarding the IRO(s): (a) identity, address, and phone number; (b) a copy of the engagement letter; (c) information to demonstrate that the IRO has the qualifications outlined in Appendix A to this CIA; (d) a summary and description of any and all current and prior engagements and agreements between Ensign Group and the IRO; and (e) a certification from the IRO regarding its professional independence and objectivity with respect to Ensign Group; 10. a description of the process by which Ensign Group fulfills the requirements of Section III.F regarding Ineligible Persons; 11. a list of all of Ensign Group’s locations (including locations and mailing addresses); the corresponding name under which each location is doing business; the corresponding phone numbers and fax numbers; each location’s Medicare and state Medicaid program provider number and/or supplier number(s); and the name and address of each Medicare and state Medicaid program contractor to which Ensign Group currently submits claims; 12. a description of Ensign Group’s corporate structure, including identification of any parent and sister companies, subsidiaries, and their respective lines of business; and

  • Recognition of U.S. Special Resolution Regimes (a) In the event a Covered Party becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer of this Agreement (and any interest and obligation in or under, and any property securing, this Agreement) from such Covered Party will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if this Agreement (and any interest and obligation in or under, and any property securing, this Agreement) were governed by the laws of the United States of America or a State of the United States of America. (b) In the event that a Covered Party or any BHC Affiliate of such Covered Party becomes subject to a proceeding under a U.S. Special Resolution Regime, any Default Right under this Agreement that may be exercised against such Covered Party is permitted to be exercised to no greater extent than such Default Right could be exercised under the U.S. Special Resolution Regime if this Agreement were governed by the laws of the United States of America or a State of the United States of America.

  • Recognition of the U.S. Special Resolution Regimes (i) In the event that any Underwriter that is a Covered Entity becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer from such Underwriter of this Agreement, and any interest and obligation in or under this Agreement, will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if this Agreement, and any such interest and obligation, were governed by the laws of the United States or a state of the United States. (ii) In the event that any Underwriter that is a Covered Entity or a BHC Act Affiliate of such Underwriter becomes subject to a proceeding under a U.S. Special Resolution Regime, Default Rights under this Agreement that may be exercised against such Underwriter are permitted to be exercised to no greater extent than such Default Rights could be exercised under the U.S. Special Resolution Regime if this Agreement were governed by the laws of the United States or a state of the United States. As used in this Section 16(e):

  • Human and Financial Resources to Implement Safeguards Requirements The Borrower shall make available necessary budgetary and human resources to fully implement the EMP and the RP.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!