No Exhibit E without unaltered DPA including Texas Addendum Any alterations are only allowed in Exhibit “H”. Any terms under Exhibit “H” do not apply to Exhibit “E” and render Exhibit “E” null and void.
Attachment A, Scope of Services The scope of services is amended as follows:
Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
Changes to Specifications All Specifications and any changes thereto agreed to by the parties from time to time shall be in writing, dated and signed by the parties. Any change to the Process shall be deemed a Specification change. No change in the Specifications shall be implemented by Catalent, whether requested by Client or requested or required by any Regulatory Authority, until the parties have agreed in writing to such change, the implementation date of such change, and any increase or decrease in costs, expenses or fees associated with such change (including any change to Unit Pricing). Catalent shall respond promptly to any request made by Client for a change in the Specifications, and both parties shall use commercially reasonable, good faith efforts to agree to the terms of such change in a timely manner. As soon as possible after a request is made for any change in Specifications, Catalent shall notify Client of the costs associated with such change and shall provide such supporting documentation as Client may reasonably require. Client shall pay all costs associated with such agreed upon changes. If there is a conflict between the terms of this Agreement and the terms of the Specifications, this Agreement shall control. Catalent reserves the right to postpone effecting changes to the Specifications until such time as the parties agree to and execute the required written amendment.
Reduction in scope of agreement for fault 19.1.1 If the Grantee does not comply with an obligation under this Agreement and the Commonwealth believes that the non‐compliance is incapable of remedy, or if the Grantee has failed to comply with a notice to remedy, the Commonwealth may by written notice reduce the scope of the Agreement.
19.1.2 The Grantee agrees, on receipt of the notice of reduction, to:
(a) stop or reduce the performance of the Grantee’s obligations as specified in the notice;
(b) take all available steps to minimise loss resulting from the reduction;
(c) continue performing any part of the Activity or the Agreement not affected by the notice if requested to do so by the Commonwealth;
(d) report on, and return any part of the Grant to the Commonwealth, or otherwise deal with the Grant, as directed by the Commonwealth.
19.1.3 In the event of reduction under clause 19.1.1, the amount of the Grant will be reduced in proportion to the reduction in the scope of the Agreement.
Background Screening VENDOR shall comply with all requirements of Sections 1012.32 and 1012.465, Florida Statutes, and all of its personnel who (1) are to be permitted access to school grounds when students are present, (2) will have direct contact with students, or (3) have access or control of school funds, will successfully complete the background screening required by the referenced statutes and meet the standards established by the statutes. This background screening will be conducted by SBBC in advance of VENDOR or its personnel providing any services under the conditions described in the previous sentence. VENDOR shall bear the cost of acquiring the background screening required by Section 1012.32, Florida Statutes, and any fee imposed by the Florida Department of Law Enforcement to maintain the fingerprints provided with respect to VENDOR and its personnel. The parties agree that the failure of VENDOR to perform any of the duties described in this section shall constitute a material breach of this Agreement entitling SBBC to terminate immediately with no further responsibilities or duties to perform under this Agreement. VENDOR agrees to indemnify and hold harmless SBBC, its officers and employees from any liability in the form of physical or mental injury, death or property damage resulting from VENDOR’s failure to comply with the requirements of this section or with Sections 1012.32 and 1012.465, Florida Statutes.
Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract. If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.
APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.
CERTIFICATION OF NO ASBESTOS CONTAINING MATERIALS OR WORK 8.1 The Contractor shall be responsible for ensuring that no asbestos containing materials or work is included within the scope of the Work. The Contractor shall take whatever measures it deems necessary to insure that all employees, suppliers, fabricators, material men, subcontractors, or their assigns, comply with this requirement.
8.2 The Contractor shall ensure that Texas Department of Health licensed individuals, consultants or companies are used for any required asbestos work including asbestos inspection, asbestos abatement plans/specifications, asbestos abatement, asbestos project management and third-party asbestos monitoring.
LIMITATIONS ON REVERSE ENGINEERING, DECOMPILATION AND DISASSEMBLY You may not reverse engineer, decompile, or disassemble the Software, except and only to the extent that such activity is expressly permitted by applicable law notwithstanding this limitation.
