Vendor’s Right to Stop Work Sample Clauses

Vendor’s Right to Stop Work. 16.4.1 Vendor may, in addition to any other rights afforded under the Contract Documents or at law, stop work for Owner’s failure to pay amounts properly due under Vendor’s Application for Payment, excepting those amounts subject to a bona fide dispute hereunder. 16.4.2 If the event set forth in Section 16.4.1 above shall occur, Vendor has the right to stop work by providing written notice to Owner that Vendor will stop work unless such event is cured within twenty (20) business days from Owner’s receipt of Vendor’s written notice. If Owner fails to cure such problem within such twenty (20) business days, then Vendor may stop work. In such case, Vendor shall be entitled to an adjustment to the Contract Price, Work Schedule and other affected terms and conditions in accordance with Article 14 to the extent it has been adversely impacted by such stoppage.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Vendor’s Right to Stop Work. 16.4.1 Vendor may, in addition to any other rights afforded under the Contract Documents or at law, stop work for Xxxxxxx’x failure to pay amounts properly due under Vendor’s Application for Payment (including those amounts not paid pursuant to Section 11.1.5), excepting those amounts subject to a bona fide dispute hereunder. Except as otherwise provided in this Agreement, all payments properly due and unpaid shall bear interest at the rate set forth in Section 11.3.1. 16.4.2 If the event set forth in Section 16.4.1 above shall occur, Vendor has the right to stop work by providing written notice to Bechtel that Vendor will stop work unless such event is cured within twenty (20) Days from Xxxxxxx’x receipt of Vendor’s notice. If Bechtel fails to cure such problem within such twenty (20) Days, then Vendor may stop work. In such case, Vendor shall be entitled to an adjustment to the Contract Price, Work Schedule and other affected terms and conditions in accordance with Article 14 to the extent it has been adversely impacted by such stoppage.
Sample 1Sample 2

Related to Vendor’s Right to Stop Work

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Lessor’s Rights If Lessee fails to perform Lessee's obligations under this Paragraph 7, or under any other paragraph of this Lease, Lessor may at its option (but shall not be required to) enter upon the Premises after ten (10) days' prior written notice to Lessee (except in the case of an emergency, in which case no notice shall be required), perform such obligations on Lessee's behalf and put the same in good order, condition and repair, and the cost thereof together with interest thereon at the maximum rate then allowable by law shall become due and payable as additional rental to Lessor together with Lessee's next rental installment.

  • Lessor’s Right to Inspect Lessee shall permit Lessor and its authorized representatives as frequently as reasonably requested by Lessor to inspect the Leased Property and Lessee’s accounts and records pertaining thereto and make copies thereof, during usual business hours upon reasonable advance Notice, subject only to any business confidentiality requirements reasonably requested by Lessee.

  • HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.

  • BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.

  • OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.

  • LESSOR'S RIGHT OF ENTRY The Lessor or the Lessor's agent may enter at reasonable hours to inspect or show the Premises to prospective lenders and purchasers, and to do anything the Lessor may be required to do hereunder or which the Lessor may deem necessary for the good of the Premises or any building of which they are apart. During the last [#] days of the Term, the Lessor may display a "For Rent" sign on the Premises and show the Premises to prospective lessees.

  • Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.

  • Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.

  • TEACHERS’ RIGHTS A. Pursuant to the Employer-Employee Relations Act, the Board and the Association agree that every member of the unit shall have the right freely to organize, join and support the Association and its affiliates for the purpose of engaging in collective negotiations and other concerted activities for mutual aid and protection, or to refrain from such activities. The Board and the Association undertake and agree that they shall not directly or indirectly discourage or deprive or coerce any teacher in the enjoyment of any rights conferred by the Employer-Employee Relations Act, or other laws of New Jersey or the constitutions of New Jersey or the United States. B. Nothing contained herein shall be construed to deny or restrict to any teacher such rights as he/she may have under New Jersey School Laws or other applicable laws and regulations. The rights granted to teachers hereunder shall be deemed to be in addition to those provided elsewhere. C. No teacher shall be disciplined, reprimanded or reduced in rank or compensation without just cause. Any such action asserted by the Board, or any agent or representative thereof, shall be subject to the grievance procedure herein set forth. For purposes of this provision, discharge, removal, or non-renewal shall not be considered as discipline, reprimand or reduction in rank or compensation. D. Whenever any teacher is required to appear before any Administrator or Supervisor, the Superintendent, Board or any committee thereof for a meeting or conference, the purpose of which adversely concerns the continuance of that teacher in his/her office, position, or employment or adversely concerns salary or any increments pertaining thereto, he/she shall be given prior written notice of the reason for such meeting or conference and shall be entitled to have a representative of the Association present to advise and represent him/her during such meeting or conference, provided that no unreasonable delay shall be incurred in the scheduling of such meeting due to a lack of representation. E. The Board shall provide a job description of co- curricular jobs for which compensation is provided. This description shall be prepared by the Board of Education in consultation with the Association.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!