Wage and Claims Adjustments Sample Clauses

Wage and Claims Adjustments. The owner shall be responsible for the correction of all violations under section 2.4, including violations committed by other contractors. In cases where there is evidence of underpayment of salaries or wages to any laborers or mechanics (including apprentices and trainees) by the owner or other contractor or a failure by the owner or other contractor to submit payrolls and related reports, the owner shall be required to place an amount in escrow, as determined by HUD sufficient to pay persons employed on the work covered by the Agreement the difference between the salaries or wages actually paid such employees for the total number of hours worked and the full amount of wages required under this Agreement, as well as an amount determined by HUD to be sufficient to satisfy any liability of the owner or other contractor for liquidated damages pursuant to section 2.4. The amounts withheld may be disbursed by HUD for and on account of the owner or other contractor to the respective employees to whom they are due, and to the Federal Government in satisfaction of liquidated damages under section 2.4.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
Wage and Claims Adjustments. The owner shall be responsible for the correction of all violations under section 2.4, including violations committed by other contractors. In cases where there is evidence of underpayment of salaries or wages to any laborers or mechanics (including apprentices and trainees) by the owner or other contractor or a failure by the owner or other contractor to submit payrolls and related reports, the owner shall be required to place an amount in escrow, as determined by HUD sufficient to pay persons employed on the work covered by the Agreement the difference between the salaries or wages actually paid such employees for the total number of hours worked and the full amount of wages required under this Agreement, as well as an amount determined by HUD to be sufficient to satisfy any liability of the owner or other contractor for liquidated damages pursuant to section 2.4. The amounts withheld may be disbursed by HUD for and on account of the owner or other contractor to the respective employees to whom they are due, and to the Federal Government in satisfaction of liquidated damages under section 2.4. Agreement to Enter into a PBV HAP Contract HUD 52531B, Part 2 of 2 Previous Editions are obsolete Page 16 of 17 (07/2019) 2.9 Reserved
Sample 1

Related to Wage and Claims Adjustments

  • Claims-made limitations The following provisions shall apply if the professional liability coverage is written on a claims-made form:

  • ADJUSTMENT OF DISPUTES 37.01 (1) The Employer and the Union recognize that grievances may arise in each of the following circumstances:

  • Settlement of Disputes between a Contracting Party and an Investor of the other Contracting Party

  • Settlement of Grievances The applicable procedures of this Agreement shall be followed for the settlement of all grievances. All grievances shall be considered carefully and processed promptly.

  • EMPLOYEE EVALUATIONS 3. Any matter for which there is recourse under State or Federal statutes.

  • Claims Excluded from Arbitration The following matters will not be subject to arbitration but will instead be adjudicated in the courts of Xxxxxx County, Texas or such other court in which jurisdiction and venue are proper: (a) an action for possession or for injunctive remedies provided under applicable landlord-tenant laws or to enforce intellectual property rights; (b) a suit by Owner or its assignee for collection of amounts owed by Resident under this Agreement; and (c) any claim or dispute for which applicable law (as determined by a binding court decision) or the applicable arbitration rules do not permit arbitration and require adjudication in a specific civil court. Matters within the jurisdiction of an applicable small claims court may also be brought in that court in lieu of arbitration.

  • Technical Objections to Grievances It is the intent of both Parties of this Agreement that no grievance shall be defeated merely because of a technical error, other than time limitations in processing the grievance through the grievance procedure. To this end, an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance, in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.

  • Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.

  • Claims and Disputes A. Claims by CONTRACTOR shall be made in writing to the COUNTY within two (2) business days after the commencement of the event giving rise to such claim or CONTRACTOR shall be deemed to have waived the claim. All claims shall be priced in accordance with the section in this document entitled “Changes in Work”.

  • Prorations and Adjustments The following shall be prorated and adjusted between Seller and Buyer as of the Closing Date, except as otherwise specified:

Time is Money Join Law Insider Premium to draft better contracts faster.