Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.
Time Limitations Neither Parent nor Acquisition Corp. shall have any liability (for indemnification or otherwise) with respect to any representation or warranty, or agreement to be performed and complied with prior to the Effective Time, unless on or before the two-year anniversary of the Effective Time (the “Claims Deadline”), Parent is given notice of a claim with respect thereto, in accordance with Section 8.05, specifying the factual basis therefor in reasonable detail to the extent then known by the Company Indemnified Parties.
Waiver of defences The obligations of each Guarantor under this Clause 17 will not be affected by an act, omission, matter or thing which, but for this Clause, would reduce, release or prejudice any of its obligations under this Clause 17 (without limitation and whether or not known to it or any Finance Party) including: (a) any time, waiver or consent granted to, or composition with, any Obligor or other person; (b) the release of any other Obligor or any other person under the terms of any composition or arrangement with any creditor of any member of the Group; (c) the taking, variation, compromise, exchange, renewal or release of, or refusal or neglect to perfect, take up or enforce, any rights against, or security over assets of, any Obligor or other person or any non-presentation or non-observance of any formality or other requirement in respect of any instrument or any failure to realise the full value of any security; (d) any incapacity or lack of power, authority or legal personality of or dissolution or change in the members or status of an Obligor or any other person; (e) any amendment, novation, supplement, extension, restatement (however fundamental and whether or not more onerous) or replacement of any Finance Document or any other document or security including without limitation any change in the purpose of, any extension of or any increase in any facility or the addition of any new facility under any Finance Document or other document or security; (f) any unenforceability, illegality or invalidity of any obligation of any person under any Finance Document or any other document or security; or (g) any insolvency or similar proceedings.
Waiver of Steps The parties may mutually agree to waive any step of the grievance procedure.
Extension of Time Periods The parties may extend any period of time provided in this Article 7 by mutual agreement.
Waiver of Landlord’s Lien To the extent permitted by Law, Lessor hereby expressly waives any and all liens (constitutional, statutory, contractual or otherwise) upon Lessee’s personal property now or hereafter installed or placed in or on the Leased Premises, which otherwise might exist to secure payment of the sums herein provided to be paid by Lessee to Lessor.
Waiver of Statutes Lessor and Lessee agree that the terms of this Lease shall govern the effect of any damage to or destruction of the Premises and the Building with respect to the termination of this Lease and hereby waive the provisions of any present or future statute to the extent it is inconsistent herewith.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Waiver of Defenses The Guarantor hereby waives any and all defenses to the performance by the Guarantor of its duties and obligations under this Guaranty, including any defense based on any of the following: (1) any failure of the Lender to disclose to the Guarantor any information relating to the business, condition (financial or otherwise), operations, performance, properties or prospects of any party obligated to make payment on any and all Guaranteed Obligations, whether as principal or guarantor, now or hereafter known to the Lender, (2) any defense to the payment of any or all the Guaranteed Obligations, including lack of validity or enforceability of any of the Guaranteed Obligations or any of the Loan Documents, any change in the time, manner or place of payment of, or in any other tern in respect of, all or any of the Guaranteed Obligations, or any other amendment or waiver of or consent to any departure from any Loan Document, (3) any exchange or release of, or non-perfection of any security interest on or in any assets securing the payment of the Guaranteed Obligations, (4) any failure to execute any other guaranty for all or any part of the Guaranteed Obligations, or any release or amendment or waiver of, or consent to any departure from, any other guaranty for any or all of the Guaranteed Obligations, (5) any subordination of any or all of the Guaranteed Obligations, (6) any act or omission of the Lender in connection with the enforcement of, or the exercise of rights and remedies, including any election of, or the order of exercising any, remedies, with respect to (a) the Guaranteed Obligations, (b) any other guarantor of the Guaranteed Obligations, or (c) any assets securing the payment of the Guaranteed Obligations, (7) any manner of application of any funds received by the Lender to Guaranteed Obligations or any other obligations owed to the Lender, whether from the sale or disposition of any assets securing the Guaranteed Obligations, from another guarantor of the Guaranteed Obligations or otherwise, and (8) any failure to give or provide any notices, demands or protests, including those specified under Section 8 herein, entitled "Waiver of Notices".
Time Limitation The time limits established in the grievance procedures shall be followed by the parties and the aggrieved employee. If the time limit procedure is not followed by the Union or the aggrieved employee, the grievance shall be considered settled without precedent. If the time procedure is not followed by the Employer, the grievance shall automatically advance to the next step, but arbitration shall only be instituted upon timely written notice by the Union. The time limits established in the grievance and arbitration procedure may be extended by mutual agreement reduced to writing and signed by the parties.
