CONTRACTUAL PENALTIES 1. Should the Accommodated Person fail to pay the price for the accommodation in the agreed amount, by the due date and under the correct variable symbol, he/she is obliged to pay interest on late payments under Section 10(2) of Act No. 176/2004 Coll., on the Disposal of the Property of Public Institutions and the Amendment to Act Xx. 000/0000 xx xxx Xxxxxxxx Xxxxxxx xx xxx Xxxxxx Xxxxxxxx, on the Slovak Forestry Chamber, as amended by Act No. 464/2002 Coll., as amended. In addition, he/she is obliged to pay a contractual penalty (even if the contractual obligations are breached not through a fault of the Accommodated Person, e.g., by error of the financial institution) in the amount of 0.3 % of the due amount for each day of delay. The agreement regarding the contractual penalty shall not affect the Landlord’s entitlement to demand compensation for damages. Both entitlements can be exercised by the Landlord concurrently. Both the contractual penalty and the interest on late payments are to be paid via a separate bank transfer to the Landlord’s account stated in Article I in the “Landlord” section hereof (separately from the price for the accommodation).
2. If the payment is to be searched for due to the incorrectly stated variable symbol, the Accommodated Person shall pay a contractual penalty amounting to EUR 5.
3. In the case of loss or theft of the accommodation card, the Accommodated Person shall pay the Landlord the sum for issuing a new card in the amount of EUR 13, and in the case of loss or theft of the key to the room, he/she shall pay the sum for making an extra key in the amount of EUR 20. The sum for issuing a new card and making an extra key is to be paid by the Accommodated person by a stand- alone wire transfer to the bank account of the Landlord provided in Article I, part “Landlord” of this Contract (separately from the price for accommodation and settlement of contractual penalties and default interest). The Landlord shall provide the Accommodated Person with a replacement key or a new accommodation ID only after the sum stipulated under this paragraph is paid.
4. In compliance with Section 544(1) of the Civil Code, the Accommodated Person is also obliged to pay the contractual penalty even though the Landlord did not incur any damage as a result of a breach of the obligations of the Accommodated Person.
Contractual Penalty If the Contractor refuses or fails to duly complete the Assignment after the Assignment Order has been awarded to the Contractor and signed in accordance with this Agreement, the Company is entitled to request the Contractor to pay a contractual penalty in the amount of 10% (ten percent) of the Fee for the respective Assignment. Should the Contractor fail to meet any of the milestones or delivery dates under any of the Assignment Orders and provided that the cause of such delay is attributable to the action or inaction of the Contractor, the Company is entitled to request the Contractor to pay to the Company a contractual penalty of 0.1% (zero point one percent) of the amount of the Fee payable for the respective Assignment for each day of delay, provided that each such contractual penalty shall not exceed 10% (ten percent) of the Fee payable for the respective Assignment. Should the Company delay any payment in accordance with Clause 5.7, the Contractor is entitled to request the Company to pay a contractual penalty in the amount of 0.1% (zero point one percent) from the delayed amount for each day of delay, provided that the total amount of such contractual penalty payable by the Company under this Clause 13.2.3 shall not exceed 10% (ten percent) of the delayed amount. The contractual penalties shall be applied upon the sole discretion of the entitled Party under the Agreement considering the material consequences of the breach. Payment of the contractual penalty shall not release the Party from performance of any of its obligations under the Agreement. FORCE MAJEURE
Work Hour Penalty Eight hours of labor constitute a legal day's work, and forty hours constitute a legal week's work. Pursuant to Section 1813 of the Labor Code of the State of California, the Contractor shall forfeit to the County Twenty Five Dollars ($25) for each worker employed in the execution of this Contract by the Contractor or by any subcontractor for each calendar day during which such worker is required or permitted to work more than the legal day's or week's work, except that work performed by employees of said Contractor and subcontractors in excess of the legal limit shall be permitted without the foregoing penalty upon the payment of compensation to the workers for all hours worked in excess of eight hours per day of not less than 1-1/2 times the basic rate of pay.
- FINANCIAL PENALTIES By virtue of the Financial Regulation applicable to the general budget of the European Communities, any beneficiary declared to be in grave breach of his obligations shall be liable to financial penalties of between 2% and 10% of the value of the grant in question, with due regard for the principle of proportionality. This rate may be increased to between 4% and 20% in the event of a repeated breach in the five years following the first. The beneficiary shall be notified in writing of any decision by the Commission to apply such financial penalties.
Judgments; Penalties One or more fines, penalties or final judgments, orders or decrees for the payment of money in an amount, individually or in the aggregate, of at least Two Hundred Fifty Thousand Dollars ($250,000.00) (not covered by independent third-party insurance as to which liability has been accepted by such insurance carrier) shall be rendered against Borrower by any Governmental Authority, and the same are not, within ten (10) days after the entry, assessment or issuance thereof, discharged, satisfied, or paid, or after execution thereof, stayed or bonded pending appeal, or such judgments are not discharged prior to the expiration of any such stay (provided that no Credit Extensions will be made prior to the satisfaction, payment, discharge, stay, or bonding of such fine, penalty, judgment, order or decree);
Civil Penalty Payment Pursuant to Health and Safety Code § 25249.7(b)(2), and in settlement of all claims alleged in the Notice or referred to in this Settlement Agreement, XR agrees to pay two thousand ($2,000.00) in civil penalties. The penalty payment will be allocated in accordance with California Health and Safety Code §§ 25249.12(c)(1) & (d), with 75% of the penalty amount paid to the California Office of Environmental Health Hazard Assessment (“OEHHA”) and the remaining 25% of the penalty amount retained by EHA. Shall issue two separate checks for the initial civil penalty payment to (a) “OEHHA” and (b) Environmental Health Advocates, Inc. as follows: One payment of $1,500.00 to OEHHA, due 14 (fourteen) days after the Effective Date. One payment of $500.00 to EHA, due 14 (fourteen) days after the Effective Date. All payments owed to OEHHA (EIN: 00-0000000), pursuant to this Section shall be delivered directly to OEHHA (Memo Line "Prop 65 Penalties") at the following addresses: P.O. Box 4010 Sacramento, CA 95812-4010 All penalty payments owed to EHA shall be sent to: Xxxxx Xxxxxx Environmental Health Advocates 000 Xxxxxxxx, Xxxxx 0000 Xxx Xxxxx, XX 00000
SUBCONTRACTUAL RELATIONS 5.3.1 By written agreement, the Contractor shall require each Subcontractor, to the extent of the Work to be performed by the Subcontractor, to be bound to the Contractor by the terms of the Contract Documents, and to assume toward the Contractor all the obligations and responsibilities
Contract Compliance All individual employee contracts entered into and/or in force during the duration of this Agreement shall be subject to and consistent with Washington State law and the terms and conditions of this Agreement. Any individual employee contract executed shall expressly provide that it is subject to the terms of this and subsequent Agreements between the District and the Association. If any individual employee contract contains any language inconsistent with this Agreement, this Agreement, during its duration, shall be controlling.
Health and Welfare Plans (a) A copy of the master contracts with the carriers for the extended health care, dental and group life plans shall be sent to the President of the Union.
(b) The Employer will consult the Union before developing any pamphlet explaining the highlights of the plans for distribution to employees. The cost of such a pamphlet shall be borne by the Employer.
Submitting False Claims; Monetary Penalties The AOC shall be entitled to remedy any false claims, as defined in California Government Code section 12650 et seq., made to the AOC by the Contractor or any Subcontractor under the standards set forth in Government Code section 12650 et seq. Any Contractor or Subcontractor who submits a false claim shall be liable to the AOC for three times the amount of damages that the AOC sustains because of the false claim. A Contractor or Subcontractor who submits a false claim shall also be liable to the AOC for (a) the costs, including attorney fees, of a civil action brought to recover any of those penalties or damages, and (b) a civil penalty of up to $10,000 for each false claim.
