Common use of Western Australia Clause in Contracts

Western Australia. (a) the appointed adjudicator or the adjudicator (as the case may be) is ; or (b) if no appointed adjudicator or adjudicator is appointed, the Resolution Institute of the Western Australian Chapter; or 3. Victoria, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 4. any other State or Territory (save for Queensland), the Resolution Institute of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 11.18(b)) CLAUSE 13 - COMPLETION Liquidated damages: (Clause 13.6) For the Subcontract Works is $ per day For each Stage is: $ per day $ per day $ per day CLAUSE 15 - DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 1.4(a)(ii), 6.5(b)(i), 6.5(c)(ii), 6.8(d)(ii), 7.3(b)(ii)B and (iii), 7.7, 8.3, 8.4(b)(ii)B, 8.4(d), 8.5(b)(ii), 8.5(c), 9.5(a), 9.7(b)(ii), 10.3(a)(ii)A, 10.3(a)(ii)B, 11.4, 13.1, 14.6(a), 17.3(e)(ii) and 17.3(e)(iii). If clause 1 of the Special Conditions applies, clause 1.1(b)(i) and clause 1.2(b) of the Special Conditions. Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Resolution Institute unless otherwise specified)

Western Australia. (a) the appointed adjudicator or the adjudicator (as the case may be) is ; or (b) if no appointed adjudicator or adjudicator is appointed, the Resolution Institute of the Western Australian Chapter; or 3. Victoria, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 4. any other State or Territory (save for Queensland), the Resolution Institute of the Chapter in that State or Territory. Limits of accuracy for quantities in Schedule of Rates: (Clause 12.23(c)) Upper Limit: (115% unless otherwise stated) Lower Limit: (85% unless otherwise stated) Facilities and infrastructure accounting (additional): (Clause 11.18(b12.21(b)) CLAUSE 13 - – COMPLETION Liquidated damagesdamages payable by Contractor when Date of Completion occurs after Date for Completion: (Clause 13.613.7) For If there are no Stages, for the Subcontract Works is is: $ per day For day. If there are Stages, for each Stage is: Stage Liquidated Damages $ per day $ per day $ per day CLAUSE 14 - TERMINATION Number of days to remedy breach: (Clauses 14.3(c) and 14.4(b)) days CLAUSE 15 - DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 1.4(a)(ii2.3(a)(ii), 6.5(b)(i4.2, 7.3(b)(i), 6.5(c)(ii7.4(a)(ii), 6.8(d)(ii8.4(c)(ii), 7.3(b)(ii)B and (iii), 7.7, 8.3, 8.4(b)(ii)B, 8.4(d), 8.5(b)(ii8.21(d)(ii), 8.5(c8.29, 9.5, 9.9(b)(i), 9.5(a9.10, 10.8, 10.11(b)(ii)B, 11.3(b), 9.7(b)(ii11.3(c)(ii), 10.3(a)(ii)A, 10.3(a)(ii)B, 11.4, 13.1, 14.6(a11.3(d), 17.3(e)(ii11.6, 12.4, 12.23(e)(ii), 13.2(b)(ii), 14.8(a), 18.4(e)(ii) and 17.3(e)(iii). If 18.4(e)(iii) and if clause 1 of the Special Conditions applies, clause 1.1(b)(i) of the Special Conditions and clause 1.2(b) of the Special Conditions. Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Resolution Institute unless otherwise specified)

Western Australia. (a) the appointed adjudicator or the adjudicator (as the case may be) is ; or (b) if no appointed adjudicator or adjudicator is appointed, the Resolution Institute of the Western Australian Chapter; or 3. Victoria, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 4. any other State or Territory (save for Queensland), the Resolution Institute of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 11.18(b12.21(b)) CLAUSE 13 - – COMPLETION Liquidated damagesdamages payable by Contractor when Date of Completion occurs after Date for Completion: (Clause 13.613.7) For If there are no Stages, for the Subcontract Works is is: $ per day For day. If there are Stages, for each Stage is: Stage Liquidated Damages $ per day $ per day $ per day CLAUSE 14 - TERMINATION Number of days to remedy breach: (Clauses 14.3(c) and 14.4(b)) days CLAUSE 15 - DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 1.4(a)(ii4.2, 7.3(b)(i), 6.5(b)(i7.4(a)(ii), 6.5(c)(ii7.5(c)(ii), 6.8(d)(ii8.4(c)(ii), 7.3(b)(ii)B and (iii), 7.7, 8.3, 8.4(b)(ii)B, 8.4(d), 8.5(b)(ii8.21(d)(ii), 8.5(c8.29, 9.5, 9.9(b)(i), 9.5(a9.10, 10.8, 10.11(b)(ii)B, 11.3(b), 9.7(b)(ii11.3(c)(ii), 10.3(a)(ii)A, 10.3(a)(ii)B, 11.4, 13.1, 14.6(a11.3(d), 17.3(e)(ii11.6, 12.4, 13.2(b)(ii), 14.8(a), 18.4(e)(ii) and 17.3(e)(iii). If 18.4(e)(iii) and if clause 1 of the Special Conditions applies, clause 1.1(b)(i) of the Special Conditions and clause 1.2(b) of the Special Conditions. Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Resolution Institute unless otherwise specified)

Western Australia. (a) the appointed adjudicator or the adjudicator (as the case may be) is ; or (b) if no appointed adjudicator or adjudicator is appointed, the Resolution Institute of the Western Australian Chapter; or 3. Victoria, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 4. any other State or Territory (save for Queensland), the Resolution Institute of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 11.18(b)) Reporting Entity: (Clauses 11.19 to 11.24) [To be inserted following selection of the successful Tenderer - noting that clauses 11.19 to 11.24 will only apply where the successful Tenderer is a Reporting Entity for the purposes of the Payment Times Procurement Connected Policy] Clauses 11.19 to 11.24 [do/do not] apply. CLAUSE 13 - COMPLETION Liquidated damagesDamages: (Clause 13.6) For the Subcontract Works is $ per day For each Stage is: Stage Liquidated Damages $ per day $ per day $ per day $ per day CLAUSE 15 - DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 1.4(a)(ii1.3(a)(ii), 6.5(b)(i), 6.5(c)(ii), 6.8(d)(ii), 7.3(b)(ii)B 7.3(b)(iii)B and (iiiiv), 7.7, 8.3, 8.4(b)(ii)B, 8.4(b)(ii)B and 8.4(d), 8.5(b)(ii), ) and 8.5(c), 9.5(a)9.5, 9.7(b)(ii), 10.3(a)(ii)A, 10.3(a)(ii)B, 11.4, 13.1, 14.6(a), 17.3(e)(ii17.4(e)(ii) and 17.3(e)(iii(iii). If clause 1 of the Special Conditions applies, clause 1.1(b)(i1.1(d) and 1.1(g) of the Special Conditions. If clause 1.2(b5 of the Special Conditions applies, clause 5(b)(i) of the Special Conditions. Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Resolution Institute unless otherwise specified)