Xxxxxx’s Right to Perform for Lessor Sample Clauses

Xxxxxx’s Right to Perform for Lessor. If Lessor shall fail to perform or comply with any of its agreements contained herein (including without limitation its obligations under Section 8.2), following applicable notice by Lessee as provided in other provisions of this Lease, Lessee shall then provide written notice to Lessor that Lessor has failed to perform or comply with an agreement or obligation hereunder and specifying the nature of the failure to perform or comply and advising Lessor that if such failure continues for (a) a period of thirty (30) days, in the case of a failure which does not impact Lessee’s business and operations at the Property, (b) a period of ten (10) days, in the case of a failure that impacts Lessee’s business and operations at the Property and (c) a period of five (5) days in the case of a failure that impacts Lessee’s business and operations at the Property in a material way or causes an interruption of Lessee’s business and operations after this notice, then Lessee shall exercise its right to perform for Lessor under this Section 8.2. Thereafter, if Lessor does not perform or comply with its agreement as specified in such notice, Lessee may perform or comply with such agreement, and the amount of payment required to be made by Lessor hereunder and made by Xxxxxx on behalf of Lessor, and the reasonable out-of-pocket third-party costs and expenses of Lessee (including reasonable attorneys’ fees and expenses) incurred in connection with the performance of or compliance with such agreement, as the case may be, together with interest thereon at the Default Rate, shall be immediately payable by Lessor to Lessee upon demand and may be offset against any Rent payment otherwise due hereunder. In addition, in the event Lessor fails to perform its obligations under Section 8.2, then, in addition to the rights above and at the cost of Lessor, (a) Lessee shall have the right to hire Persons (as selected by Lessee in its reasonable discretion) to perform such obligations of Lessor and (b) Lessor shall cooperate with Xxxxxx, and the Persons hired by Xxxxxx, in the performance thereof. Notwithstanding the foregoing, Lessee shall not be obligated to provide the notice required under this Section 18.2 in the event of an emergency.
Sample 1
AutoNDA by SimpleDocs

Related to Xxxxxx’s Right to Perform for Lessor

  • Owner’s Right to Perform Work The Owner reserves the right to perform construction or operations related to the Project with Separate Contractors on the Site. If the Contractor claims that delay or additional cost is because of such action by the Owner, the Contractor shall assert such claims as provided in Section 5, Part 2 of the General Conditions.

  • OWNER’S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS § 7.4.1 The Owner reserves the right to perform construction or operations related to the Project with the Owner’s own forces, and to award separate contracts in connection with other portions of the Project.

  • Contractor’s Right to Terminate for Cause Contractor may terminate this Contract immediately upon written notice to Agency, or at such later date as Contractor may establish in such notice, if Agency is in default under Section 14.4.

  • LANDLORD'S RIGHT TO ENTER Landlord and its agents shall have the right to enter the Leased Premises during normal business hours after giving Tenant reasonable notice and subject to Tenant’s reasonable security measures for the purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Outside Areas during normal business hours for purposes of (i) inspecting the exterior of the Building and the Outside Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least thirty days’ prior written notice of any work to be performed on the Leased Premises); and (iii) supplying any services to be provided by Landlord. Any entry into the Leased Premises or the Outside Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof.

  • City’s Right to Terminate for Default Contractor’s failure to satisfactorily perform any obligation required by this Contract constitutes a default. Examples of default include a determination by City that Contractor has: (1) failed to deliver goods and/or perform the services of the required quality or within the time specified; (2) failed to perform any of the obligations of this Contract; and (3) failed to make sufficient progress in performance which may jeopardize full performance.

  • Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Landlord’s Rights Landlord, Agent and their respective agents, employees and representatives shall have the right to enter and/or pass through the Premises at any time or times upon reasonable prior notice (except in the event of emergency): (a) to examine and inspect the Premises and to show them to actual and prospective lenders, prospective purchasers or mortgagees of the Property or providers of capital to Landlord and its affiliates; and (b) to make such repairs, alterations, additions and improvements in or to all or any portion of either or both of the Premises and the Property, or the Property’s facilities and equipment as Landlord is required or desires to make. Landlord and Agent shall be allowed to take all materials into and upon the Premises that may be required in connection with any repairs, alterations, additions or improvements, without any liability to Tenant and without any reduction or modification of Tenant’s covenants and obligations hereunder; provided, however, that Landlord shall use reasonable efforts to limit interference with Tenant’s business operations and Tenant’s occupancy and use of the Premises. During the period of six months prior to the Expiration Date (or at any time, if Tenant has vacated or abandoned the Premises or is otherwise in default under this Lease), Landlord and its agents may exhibit the Premises to prospective tenants. Additionally, Landlord and Agent shall have the following rights with respect to the Premises, exercisable without notice to Tenant, without liability to Tenant, and without being deemed an eviction or disturbance of Tenant’s use or possession of the Premises or giving rise to any claim for setoff or abatement of Rent: (i) to designate and approve, prior to installation, all types of signs; (ii) to have pass keys, access cards, or both, to the Premises; and (iii) to decorate, remodel, repair, alter or otherwise prepare the Premises for reoccupancy at any time after Tenant vacates or abandons the Premises for more than 30 consecutive days or without notice to Landlord of Tenant’s intention to reoccupy the Premises.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • STATE's Right to Suspend the Operations The STATE and/or the STATE's Authorized Representative has the authority to suspend portions or all of the operations due to causes including, but not limited to:

  • Xxxxxxxx’s Right to Reinstate After Acceleration If Borrower meets certain conditions, Borrower shall have the right to have enforcement of this Security Instrument discontinued at any time prior to the earliest of: (a) five days before sale of the Property pursuant to any power of sale contained in this Security Instrument; (b) such other period as Applicable Law might specify for the termination of Borrower’s right to reinstate; or (c) entry of a judgment enforcing this Security Instrument. Those conditions are that Borrower: (a) pays Lender all sums which then would be due under this Security Instrument and the Note as if no acceleration had occurred; (b) cures any default of any other covenants or agreements; (c) pays all expenses incurred in enforcing this Security Instrument, including, but not limited to, reasonable attorneys’ fees, property inspection and valuation fees, and other fees incurred for the purpose of protecting Lender’s interest in the Property and rights under this Security Instrument; and (d) takes such action as Lender may reasonably require to assure that Xxxxxx’s interest in the Property and rights under this Security Instrument, and Borrower’s obligation to pay the sums secured by this Security Instrument, shall continue unchanged. Lender may require that Borrower pay such reinstatement sums and expenses in one or more of the following forms, as selected by Lender: (a) cash; (b) money order; (c) certified check, bank check, treasurer’s check or cashier’s check, provided any such check is drawn upon an institution whose deposits are insured by a federal agency, instrumentality or entity; or (d)

Time is Money Join Law Insider Premium to draft better contracts faster.