Anticipated Date of Practical Completion definition

Anticipated Date of Practical Completion means the expected dated of completion of building works being [DD/MMM/YYYY] or such other date as the Grant Recipient may notify pursuant to clause 11 of this Agreement;
Sample 1Sample 2Sample 3
Anticipated Date of Practical Completion means a future date to be agreed by the Authority and the Contractor by which all Works required under the terms of this Agreement must be completed;
Sample 1

Examples of Anticipated Date of Practical Completion in a sentence

  • The Contractor shall commence the Works on the Agreement Date and, subject to the provisions of clause 21.1.6, complete Phase 1 by the Anticipated Date of Phase 1 Practical Completion, complete each Phase 2 Stage by the Anticipated Date of Phase 2 Stage Practical Completion and complete all remaining Works by the Anticipated Date of Practical Completion.

  • Anticipated Date of Practical Completion means in relation to a Works Portion, the date which the Independent Certifier certifies in writing to the State and the Developer pursuant to clause 20.2(a), as being the date that is likely to be the date on which Practical Completion of that Works Portion will be achieved.

  • In the event that the Contractor is delayed or is likely to be delayed in completing the relevant Works on or before the Anticipated Date of Phase 1 Practical Completion, the Anticipated Date of Phase 2 Stage Practical Completion, or the Anticipated Date of Practical Completion (as the case may be), it shall notify the Authority as soon as it becomes aware of such delay or potential delay.

Related to Anticipated Date of Practical Completion

  • Date of Practical Completion means the date certified in the QBCC Form 7 - Certificate of Practical Completion in accordance with Condition 28.

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Final Completion Date means the date on which Final Completion occurs.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Billing Commencement Date means the earlier of:

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Service Commencement Date in respect of a Service or a particular instance of a Service means the date on which that particular Service or particular instance of a Service is first provided to the Customer, or as otherwise explicitly set out in this Agreement;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.