Capital Maintenance definition

Capital Maintenance. Contract or CMC means the Capital Maintenance Agreement and these CMA General Conditions, including all exhibits attached hereto, as such may be amended, supplemented, amended and restated or otherwise modified from time to time in accordance with the terms of the CMC.

Split View

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Get StartedBook a Demo

Capital Maintenance means maintenance or rehabilitation performed either (i) to extend the useful life of a facility, system, or component, or (ii) to restore a Public-Private Facility to the condition required upon expiration of the Public-Private Agreement.

Capital Maintenance means as defined in N.J.A.C. 6A:[26A-1.3]26-1.2.

Examples of Capital Maintenance in a sentence

• This Section 10.3.1 shall not apply to, or limit DB Contractor’s obligations, under the Capital Maintenance Agreement.

• In lieu of reimbursement, TxDOT may elect, in its discretion, to deduct such amounts from any amounts payable to DB Contractor under this Capital Maintenance Contract.

• Upon Substantial Completion, TxDOT shall assume the maintenance obligations (except for landscape maintenance during the establishment period in accordance with Good Industry Practice); provided, however, that, upon the issuance of Maintenance NTP1 under the Capital Maintenance Agreement, the Maintenance Contractor shall be responsible for the Maintenance Services pursuant to the terms of the Maintenance Agreement Documents.

• DB Contractor hereby assumes responsibility for all such matters, and acknowledges and agrees that assumption by DB Contractor of responsibility for such risks, and the consequences and costs and delays resulting therefrom, is reasonable under the circumstances of this Capital Maintenance Contract and that contingencies included in the Maintenance Price in DB Contractor’s sole judgment, constitute sufficient consideration for its acceptance and assumption of said risks and responsibilities.

• Prior to execution of this Capital Maintenance Contract, DB Contractor delivered to TxDOT one copy of all cost, unit pricing, price quote and other documentary information used in preparation of the Maintenance Price (the “EPDs”).

More Definitions of Capital Maintenance

Capital Maintenance means as defined in N.J.A.C. 6A:26-1.2. "Capital outlay" means capital outlay as defined in GAAP. "Capital project" means as defined in N.J.A.C. 6A:26-1.2.

Capital Maintenance means maintenance or rehabilitation

Capital Maintenance means maintenance intended to extend the useful life of a school facility, including upgrades and replacements of building systems, such as structure, enclosure,

Capital Maintenance means maintenance intended to extend the useful life of a school facility, including upgrades and replacements of building systems, such as structure, enclosure, mechanical, plumbing and electrical systems, and can be considered to constitute or be part of a school facilities project.

Capital Maintenance means maintenance expenditure that increases the useful life and functional

Capital Maintenance means the portion of the Project Development Plan providing the information requested in Section 4.5 of Exhibit B to the ITP.

Capital Maintenance means in relation to public transportation projects, the direct cost of any work necessary for preserving or maintaining the useful life of public transportation projects, provided the work is associated with the acquisition, installation, and/or rehabilitation of components, which are not included in the normal operating maintenance of equipment and facilities or replaced on a scheduled basis. The work shall ensure the useful life of the project for not less than five years.