Notice to Proceed means notice issued by the OPWC pursuant to Section IV of this Agreement. "OPWC" means the Ohio Public Works Commission created pursuant to Revised Code Section 164.02.
Full Notice to Proceed means that all material third party contractors have been given the notice to proceed with construction by the Capacity Market Seller or its agent, with a guaranteed completion date backed by liquidated damages.
Notice to Proceed (NTP) means the authorization issued by the CO to start performance on this Contract.
Request to Proceed means the written request from Recipient to the OPWC submitted pursuant to Section IV of this Agreement. "State" means the State of Ohio.
EPC Contractor means the contractor responsible for engineering, procurement and construction of the Facility, including Seller if acting as contractor, and including all subcontractors.
O&M Contractor means the person, if any, with whom the Concessionaire has entered into an O&M Contract for discharging O&M obligations for and on behalf of the Concessionaire;
Court appointed special advocate means a volunteer guardian ad litem appointed by the court who is responsible for: researching the background of assigned child abuse, neglect and dependency cases; representing the child's best interests; speaking for the child in all hearings, reviews and other relevant case activities; monitoring the child during the life of the case; and advocating for a safe and permanent home for the child.
Construction sign means a sign which identifies the architect, engineers, contractors and other individuals or firms involved with the construction of a building, or announces the character of the building or enterprise, which is erected during the building construction period.
Construction Service Agreement means either an Interconnection Construction Service Agreement or an Upgrade Construction Service Agreement.
Joint Operating Agreement (JOA) means the operating and participating agreement between the Parties constituting the Contractor that governs their operational activities, obligations and responsibilities under this Contract,
Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.
Interconnection Construction Service Agreement means the agreement entered into by an Interconnection Customer, Interconnected Transmission Owner and the Transmission Provider pursuant to Tariff, Part VI, Subpart B and in the form set forth in Tariff, Attachment P, relating to construction of Attachment Facilities, Network Upgrades, and/or Local Upgrades and coordination of the construction and interconnection of an associated Customer Facility. A separate Interconnection Construction Service Agreement will be executed with each Transmission Owner that is responsible for construction of any Attachment Facilities, Network Upgrades, or Local Upgrades associated with interconnection of a Customer Facility.
Engineer’s Representative means the official in the civil/ electrical engineering department who is authorized to be in-charge of the work to which these presents relate. It shall include any other official nominated to attend to the supervision of day to day execution of the work to which this CONTRACT relates.
The Sub-Contractor means any person, firm or company (other than the Contractor) to whom any part of the work has been entrusted by the Contractor with the written consent of the Engineer-In-Charge and the legal representative successors and permitted assignee of such person, firm or company.
Construction Manager means a competent person responsible for the management of the physical construction processes and the coordination, administration and management of resources on a construction site;
Contractor’s Representative means the individual authorised to act on behalf of the Contractor for the purposes of the Contract. The initial Contractor’s representative is as indicated in the Form of Agreement.
Contractor Parties means a Contractor’s members, directors, officers, shareholders, partners, managers, principal officers, representatives, agents, servants, consultants, employees or any one of them or any other person or entity with whom the Contractor is in privity of oral or written contract (e.g. subcontractor) and the Contractor intends for such other person or entity to perform under the Contract in any capacity. For the purpose of this Contract, vendors of support services, not otherwise known as human service providers or educators, shall not be considered subcontractors, e.g. lawn care, unless such activity is considered part of a training, vocational or educational program.
AS WITNESS Name: AS WITNESS: Name:
Sub-Contractor means the person named in the Contract for any part of the works or any person to whom any part of the contract has been sublet by the contractor with the consent in writing of the Engineer-in-charge and will include the legal representatives, successors and permitted assigns of such persons.
O&M Agreement means the agreement(s), if any, between the Company and the O&M Contractor for the operation and maintenance of the Facility to be entered into between the Company and the O&M Contractor, as amended or superseded from time to time;
Construction Management Agreement means the Construction Management Agreement, dated as of the date of the Common Agreement, between Construction Manager and the Project Company.
EPC means engineering, procurement and construction;
Procurement Representative means the person authorized by ULA’s cognizant procurement organization to administer and/or execute this Contract.
train operator means any person who is authorised to act as the operator of a train by a licence under section 8 of the Railways Act 1993.
Owner’s Representative has the meaning given in Section 2.2.
Consortium Agreement means this consortium agreement as well as the pre-amble and all annexes hereto;