Completion of Remedial Action definition

Completion of Remedial Action means the point when [Entity performing the work] has performed all necessary response actions on the Property, including implementation of LUCs, except for Long-Term Obligations and EPA has certified completion of remedial action pursuant to Section [?] of the AOC.
Sample 1Sample 2Sample 3
Completion of Remedial Action means the point in time when FORA has performed all necessary response actions, including establishment of all required Land Use Controls, on a given site or parcel of property, except for long-term operation and maintenance, and EPA has issued a Certificate of Completion of Remedial Action pursuant to Section XVII. of the AOC.
Sample 1

Examples of Completion of Remedial Action in a sentence

  • With respect to future liability, these covenants not to sue shall take effect upon Certification of Completion of Remedial Action by EPA pursuant to Paragraph 44.b. These covenants not to sue are conditioned upon the satisfactory performance by Settling Defendants of their obligations under this Consent Decree.

  • After Certification of Completion of Remedial Action by EPA pursuant to Subparagraph 44.b, Settling Defendants shall perform O&M and Post-Remedy Institutional Controls Work as required by the ROD, the Final Operation and Maintenance Plan, and the Institutional Controls Plan.

  • For any such costs incurred and billed after Certification of Completion of Remedial Action by EPA pursuant to Subparagraph 44.b, notice of any such objection shall be given in writing within 30 days of receipt of the bill.

  • For any such costs incurred and billed before Certification of Completion of Remedial Action by EPA pursuant to Subparagraph 44.b, notice of any such objection shall be submitted in writing as provided by Subparagraph 5.c of Appendix C.

  • With respect to future liability, these covenants shall take effect upon Certification of Completion of Remedial Action by EPA pursuant to Paragraph 50.b of Section XIV (Certification of Completion).

  • With respect to future liability, EPA’s covenant shall take effect upon Certification of Completion of Remedial Action by EPA pursuant toParagraph 50.b of Section XIV (Certification of Completion).

  • Subsequently, the Settling PRPs’ consultant, GZA GeoEnvironmental Inc., submitted a Report of Completion of Remedial Action in October 1999.

  • The Division’s Project Coordinator will schedule meetings (including by telephone conference) with EPA to review semi-annual and annual reports during construction of the Remedial Action, and at least annually during the first five years after Certification of Completion of Remedial Action Construction (as described in Paragraph 171), and in conjunction with each Periodic Review performed under Section IX, to provide updates on the status and progression of the Work.

  • With respect to future liability, these covenants shall take effect upon Certification of Completion of Remedial Action by EPA pursuant to Paragraph 51.b of Section XIV (Certification of Completion).

  • With respect to future liability, these covenants not to sue or take administrative action shall take effect upon Certification of Completion of Remedial Action by EPA pursuant to Paragraph 52(b) of Section XIV (Certification of Completion).

Related to Completion of Remedial Action

  • Remedial Action means all actions to (i) clean up, remove, treat, or in any other way address any Hazardous Material, (ii) prevent the Release of any Hazardous Material so it does not endanger or threaten to endanger public health or welfare or the indoor or outdoor environment, (iii) perform pre-remedial studies and investigations or post-remedial monitoring and care, or (iv) correct a condition of noncompliance with Environmental Laws.

  • Remedial Actions means those actions taken in the event of a radioactive release or threatened release into the environment to prevent or minimize the radioactive release so that it does not migrate and cause significant danger to the present or future public health, safety, or welfare, or to the environment. Remedial action includes, but is not limited to, actions at the location of the release such as storage, confinement, perimeter protection which may include using dikes, trenches, and ditches, clay cover, neutralization, dredging or excavation, repair or replacement of leaking containers, collection of leachate and runoff, efforts to minimize the social and economic harm of processing, provision of alternative water supplies, and any required monitoring to assure that the actions taken are sufficient to protect the public health, safety, and welfare, and the environment.

  • Remedial Action Plan has the meaning in Section 2.4.

  • Debilitating medical condition means one or more of the following:

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Imminent danger to the health and safety of the public means the existence of any condition or practice, or any violation of a permit or other requirement of this article, in a surface coal mining and reclamation operation which could reasonably be expected to cause substantial physical harm to persons outside the permit area before such condition, practice, or violation can be abated. A reasonable expectation of death or serious injury before abatement exists if a rational person, subjected to the same conditions, or practices giving rise to the peril, would not expose himself to the danger during the time necessary for abatement.

  • remedial and "response action" include the types of activities covered by the United States Comprehensive Environmental Response, Compensation and Liability Act of 1980 (CERCLA).

  • Mold remediation in accordance with professional standards means mold remediation of that

  • Subproject means a specific project to be carried out by an existing BE utilizing the proceeds of a Sub-loan or Investment, as hereinafter defined, fulfilling the conditions set forth in Part A of Schedule 4 to this Agreement;

  • Serious Medical Condition means, for the purpose of interpreting Overseas Emergency Medical Evacuation and Repatriation cover, a condition which in the opinion of the Company or its authorised representatives constitutes a serious or life threatening medical emergency requiring immediate evacuation to obtain urgent remedial treatment in order to avoid death or serious impairment to an Insured Person’s immediate or long-term health prospects. The seriousness of the medical condition will be judged within the context of the Insured Person’s geographical location and the local availability of appropriate medical care or facilities.

  • Remediation means any response, remedial, removal, or corrective action, any activity to cleanup, detoxify, decontaminate, contain or otherwise remediate any Hazardous Materials, Regulated Substances or USTs, any actions to prevent, cure or mitigate any Release, any action to comply with any Environmental Laws or with any permits issued pursuant thereto, any inspection, investigation, study, monitoring, assessment, audit, sampling and testing, laboratory or other analysis, or any evaluation relating to any Hazardous Materials, Regulated Substances or USTs.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Detoxification means a process whereby an alcohol or drug intoxicated, or alcohol or drug dependent, individual is assisted through the period of time necessary to eliminate, by metabolic or other means, the intoxicating alcohol or drug, alcohol or drug dependent factors, or alcohol in combination with drugs, as determined by a licensed Health Professional, while keeping the physiological risk to the individual at a minimum.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Phase I Environmental Assessment A “Phase I assessment” as described in, and meeting the criteria of, the ASTM, plus a radon and asbestos inspection.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Pre-existing Medical Condition means any condition which:

  • Improvement completion assurance means a surety bond, letter of credit,