Completion of the Facilities definition

Completion of the Facilities means that the Facilities (or a specific part thereof where specific parts are specified in the Scope of Work) have been completed operationally and structurally and put in a tight and clean condition and that all work in respect of Commissioning of the Facilities or such specific part thereof has been completed as per the Scope of Work.
Sample 1Sample 2Sample 3
Completion of the Facilities means the Facilities have been completed and accepted when commissioned as per Clause 25 (Commissioning).
Sample 1Sample 2
Completion of the Facilities means the Facilities have been completed and accepted when commissioned as per Clause 25 (Commissioning), Performance Guarantee parameters established as per Clause 27 and Final Acceptance certificate issued as per Clause 28 hereof.
Sample 1

Examples of Completion of the Facilities in a sentence

  • Time for Completion” means the time within which Completion of the Facilities is to be attained in accordance with the scope of work and specifications, as a whole (or of a part of the Facilities where a separate Time for Completion of such part has been prescribed in the SCC) and “Taking Over” by the Employer is to be attained.

  • The Contractor shall, unless specifically excluded in the Contract, perform all such work and/or supply all such items and materials not specifically mentioned in the Contract but that can be reasonably inferred from the Contract as being required for attaining Completion of the Facilities as if such work and/or items and materials were expressly mentioned in the Contract.

  • Completion Time Guarantee 21.1 The Contractor guarantees that it shall attain Completion of the Facilities (or a part for which a separate time for completion is specified in the SCC) within the Time for Completion specified in the SCC pursuant to GCC Sub-Clause 4.2, or within such extended time to which the Contractor shall be entitled under GCC Clause 34 hereof.

  • The Defect Liability Period shall be eighteen (18) months from the date of Completion of the Facilities (or any part thereof) or twelve (12) months from the date of Operational Acceptance of the Facilities (or any part thereof), whichever first occurs, unless specified otherwise in the SCC.

  • The Implementing Partner shall be responsible for the care and custody of the Facilities or any part thereof until the date of Completion of the Facilities pursuant to GCC Clause 24 (Completion of the Facilities) or, where the Contract provides for Completion of the Facilities in parts, until the date of Completion of the relevant part, and shall make good at its own cost any loss or damage that may occur to the Facilities or the relevant part thereof from any cause whatsoever during such period.

  • Such payment shall completely satisfy the Successful bidder, on whom award is made/Implementing Partner/Consultant obligation to attain Completion of the Facilities or the relevant part thereof within the Time for Completion or any extension thereof under ITB Clause 2.23.

  • Once the “Maximum” is reached, the Employer may consider termination of the Contract, pursuant to GCC Sub-Clause 42.2.2. Such payment shall completely satisfy the Contractor’s obligation to attain Completion of the Facilities or the relevant part thereof within the Time for Completion or any extension thereof under GCC Clause 40.

  • Delay beyond slack period will attract liquidated damages for the period of delay including slack period.No bonus will be given for earlier Completion of the Facilities or part thereof.

  • Completion Time Guarantee‌ 21.1 The Contractor guarantees that it shall attain Completion of the Facilities (or a part for which a separate time for completion is specified in the SCC) within the Time for Completion specified in the SCC pursuant to GCC Sub-Clause 4.2, or within such extended time to which the Contractor shall be entitled under GCC Clause 34 hereof.

  • Covering physical loss or damage to the Facilities at the Site,occurring prior to Completion of the Facilities, with an extendedmaintenance coverage for the Implementing Partner’s liability in respect of any loss or damage occurring during the Defect Liability Period while the Implementing Partner is on the Site for the purpose of performing its obligations during the Defect Liability Period.


More Definitions of Completion of the Facilities

Completion of the Facilities means the Facilities have been commissioned as per clause Commissioning in this contract document. The Facilities will be considered completed in all respects and accepted when performance guarantee parameters are established as per Clause Performance Guarantee Test and Final Acceptance Certificate has been issued by the IRCTC.
Sample 1
Completion of the Facilities means the Facilities have been commissioned as per Clause 25 (Commissioning).
Sample 1

Related to Completion of the Facilities

  • Project Facilities means all the amenities and facilities situated on the Site, as described in Schedule-C;

  • Marijuana testing facility means an entity licensed to analyze and certify the safety and potency of marijuana.

  • Generating Facility means the Generating Unit(s) comprising Seller’s power plant, as more particularly described in Section 1.02 and Exhibit B, including all other materials, equipment, systems, structures, features and improvements necessary to produce electric energy and thermal energy, excluding the Site, land rights and interests in land.

  • Facilities means the Plant and Equipment to be supplied and installed, as well as all the Installation Services to be carried out by the Contractor under the Contract.

  • Interconnection Facilities means the Transmission Owner Interconnection Facilities and the Customer Interconnection Facilities.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • LNG facility means a terminal which is used for the liquefaction of natural gas or the importation, offloading, and re-gasification of LNG, and includes ancillary services and temporary storage necessary for the re-gasification process and subsequent delivery to the transmission system, but does not include any part of LNG terminals used for storage;