Delayed Delivery Period definition

Delayed Delivery Period means the period commencing on the day that occurs immediately following the Outside Delivery Date and continuing until the date upon which the applicable portion of the Premises is delivered to Tenant. Notwithstanding anything contained herein to the contrary, if any portion of the Phase 1 Premises is not delivered to Tenant on or before the date that is two hundred seventy (270) days following the anticipated delivery date for such portion of the Phase 1 Premises set forth in Sections 3.2.1, 3.2.2 and 3.2.3 of the Summary (each such date, a “Phase 1 Termination Outside Date”), then Tenant shall have the right to deliver a written notice to Landlord (a “Termination Notice”) electing to terminate this Lease in its entirety effective upon the date occurring five (5) business days following receipt by Landlord of the Termination Notice (the “Effective Termination Date”). If Tenant timely delivers such a Termination Notice to Landlord, then Landlord shall have the right to suspend the occurrence of the Effective Termination Date for a period ending thirty (30) days after the applicable Phase 1 Termination Outside Date by delivering written notice to Tenant prior to the Effective Termination Date stating that, in Landlord’s reasonable, good faith judgment, the applicable portion of the Phase 1 Premises will be delivered to Tenant within thirty (30) days after the applicable Phase 1 Termination Outside Date. If the applicable portion of the Phase 1 Premises is delivered to Tenant within such thirty (30) day suspension period, then the Termination Notice shall be of no force or effect, but if the applicable portion of the Phase 1 Premises is not delivered to Tenant within such thirty (30) day suspension period, then this Lease shall terminate in its entirety and be of no further force or effect upon the expiration of such thirty (30) day suspension period and Landlord shall promptly refund to Tenant any prepaid Rent paid by Tenant to Landlord
Delayed Delivery Period means each day after the Outside Date through the Lease Commencement Date, but excluding any delay to the Commencement Date as a result of (A) any delay in Tenant’s execution of this Lease and delivery thereof to Landlord beyond February 28, 2014, (B) any Tenant Delay and/or (C) any event of Force Majeure.
Delayed Delivery Period means each day after the Abatement Outside Date until the Expansion Possession Date occurs (after deducting the number of days of tenant delays and/or delays arising from events of Force Majeure, if any). Consequently, effective upon the Expansion Commencement Date, the Existing Premises shall be increased to include the Expansion Premises. Landlord and Tenant hereby acknowledge that such addition of the Expansion Premises to the Existing Premises shall, effective as of the Expansion Commencement Date, increase the size of the Premises to approximately 29,732 rentable square feet. The Existing Premises and the Expansion Premises may hereinafter collectively be referred to as the "Premises." In connection with the Expansion Premises, Tenant shall be entitled all utilities, facilities, services (including services related to maintenance, repair and restoration) as are provided under the Lease amended hereby including, but not limited to, the utilities, facilities and services provided under Articles 8, 11, Section 12.2 and Section 12.3, and the terms of Articles 14 and 15 shall apply to Tenant’s lease of the Expansion Premises. All references in the Lease, as amended, to the Building shall mean (i) the Existing Building when the context applies to the Existing Building or any portion of the Premises (i.e., the Existing Premises) located in the Existing Building, (ii) the Expansion Building when the context applies to the Expansion Building or any portion of the Premises (i.e., the Expansion Premises) located in the Expansion Building, and (iii) both the Existing Building and the Expansion Building when the context applies to both of such buildings.

Examples of Delayed Delivery Period in a sentence

  • For purposes of this Second Amendment, "Delayed Delivery Period" shall mean each day after the Abatement Outside Date until the Expansion Possession Date occurs (after deducting the number of days of tenant delays and/or delays arising from events of Force Majeure, if any).

  • For purposes of this Lease, the "Delayed Delivery Period" shall mean the period commencing on the day that occurs immediately following the Outside Delivery Date and continuing until the date upon which the Possession Date occurs for the applicable portion of the Premises.

  • Tenant shall receive one day of abatement, with respect to the Expansion Premises only, for each day of the "Delayed Delivery Period" (defined below).


More Definitions of Delayed Delivery Period

Delayed Delivery Period is defined in Section 5.7(c)(ii)(B).

Related to Delayed Delivery Period

  • Delivery Period means that period agreed in writing between the Parties in relation to Delivery of the Product or parts thereof by the Contractor, any delay in which shall be deemed a breach of this Agreement and entitle JOBURG MARKET to exercise its remedies in terms of this Agreement or at law.

  • Delayed Delivery Fee shall have the meaning specified in paragraph 2H(2).

  • Prospectus Delivery Period means such period of time after the first date of the public offering of the Shares as in the opinion of counsel for the Underwriters a prospectus relating to the Shares is required by law to be delivered (or required to be delivered but for Rule 172 under the Securities Act) in connection with sales of the Shares by any Underwriter or dealer.

  • Discovery Period means the period of time specified in Extension 4.4, immediately following the termination of this policy during which written notice may be given to the insurer of any claim first made against the insured during such period of time for any wrongful act occurring prior to the end of the policy period and otherwise covered by this policy.

  • Delivery Period Termination Date Has the meaning specified in the Related Pass Through Trust Supplement.

  • Scheduled Delivery Date means the Date on which the Seller is required to start delivering the power at the Delivery Point as per the terms and conditions of the PPA;

  • Recovery Period means the three completed fiscal years immediately preceding the date that the Company is required to prepare the accounting restatement described in this Policy, all as determined pursuant to Rule 10D-1, and any transition period of less than nine months that is within or immediately following such three fiscal years.

  • First Delivery Date means the first date by which the commodity for a Futures Contract can be delivered in order for the terms of the Futures Contract to be fulfilled.

  • Share Delivery Date shall have the meaning set forth in Section 4(c)(ii).

  • Shelf Period has the meaning set forth in Section 2.02(b).

  • Warrant Share Delivery Date shall have the meaning set forth in Section 2(d)(i).

  • Agreement End Date has the meaning specified in Section 10.1(e).

  • Initial Negotiation End Date has the meaning set forth in Section 12.2(a).

  • Share Delivery Quantity For any Settlement Date, a number of Shares, as calculated by the Calculation Agent, equal to the Net Share Settlement Amount for such Settlement Date divided by the Settlement Price on the Valuation Date for such Settlement Date. Net Share Settlement Amount: For any Settlement Date, an amount equal to the product of (i) the number of Warrants exercised or deemed exercised on the relevant Exercise Date, (ii) the Strike Price Differential for the relevant Valuation Date and (iii) the Warrant Entitlement.

  • Initial Delivery Date has the meaning set forth in Section 1.1(d).

  • Preliminary Purchase Event means any of the following events:

  • Initial Offering Period means the period commencing with the initial effective date of the Prospectus and terminating no later than the ninetieth (90th) day following such date unless extended for up to an additional 90 days at the sole discretion of the General Partner.

  • Termination Delivery Unit means (a) in the case of a Termination Event, an Event of Default or an Extraordinary Event (other than an Insolvency, Nationalization, Merger Event or Tender Offer), one Share or (b) in the case of an Insolvency, Nationalization, Merger Event or Tender Offer, a unit consisting of the number or amount of each type of property received by a holder of one Share (without consideration of any requirement to pay cash or other consideration in lieu of fractional amounts of any securities) in such Insolvency, Nationalization, Merger Event or Tender Offer. If a Termination Delivery Unit consists of property other than cash or New Shares and Counterparty provides irrevocable written notice to the Calculation Agent on or prior to the Closing Date that it elects to deliver cash, New Shares or a combination thereof (in such proportion as Counterparty designates) in lieu of such other property, the Calculation Agent shall replace such property with cash, New Shares or a combination thereof as components of a Termination Delivery Unit in such amounts, as determined by the Calculation Agent in its discretion by commercially reasonable means, as shall have a value equal to the value of the property so replaced. If such Insolvency, Nationalization, Merger Event or Tender Offer involves a choice of consideration to be received by holders, such holder shall be deemed to have elected to receive the maximum possible amount of cash.

  • Delivery Year means the Planning Period for which a Capacity Resource is committed pursuant to the auction procedures specified in Tariff, Attachment DD, or pursuant to an FRR Capacity Plan under Reliability Assurance Agreement, Schedule 8.1. Demand Bid:

  • Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.

  • Delivery Term has the meaning set forth in Section 1.1(b).