Guaranteed Provisional Acceptance Date definition

Guaranteed Provisional Acceptance Date means February 28, 2001, which date is subject to adjustment as expressly provided in this Agreement.
Sample 1Sample 2Sample 3
Guaranteed Provisional Acceptance Date means February 15, 2002, which date is subject to adjustment as expressly provided in this Agreement";
Sample 1
Guaranteed Provisional Acceptance Date has the meaning set forth in the EPC Contract.
Sample 1Sample 2

Examples of Guaranteed Provisional Acceptance Date in a sentence

  • Contractor shall provide all such Instruction Manuals relevant to the Project not later than six (6) months prior to the Guaranteed Provisional Acceptance Date.

  • Owner shall arrange for the Fuel Supplier's natural gas pipeline system to be made available for interconnection with the Facility at the interconnection point identified in Appendix A hereto, with such facilities to be scheduled to be so available for such interconnection twenty-one (21) weeks prior to the Guaranteed Provisional Acceptance Date (provided that Contractor has made the Facility available as reasonably required to permit such interconnection to be made).

  • Contractor guarantees that (i) at least one of Provisional Acceptance, Interim Acceptance or Final Acceptance of the Facility shall be achieved on or before the Guaranteed Provisional Acceptance Date; and (ii) Final Acceptance of the Facility shall be achieved on or before the Guaranteed Final Acceptance Date.

  • Owner and Contractor hereby acknowledge and agree that the terms, conditions and amounts fixed pursuant to Section 7.2 for Provisional Acceptance Late Completion Payments are reasonable, considering the reduction in value of the Project and the increased costs that it is anticipated Owner will incur in the event of Contractor's failure to achieve at least one of Provisional Acceptance, Interim Acceptance or Final Acceptance of the Facility by the Guaranteed Provisional Acceptance Date.

  • Owner shall arrange for the Utility's electrical interconnection facilities between the Electrical Interconnection Point and the Utility's transmission system to be constructed and made available for interconnection with the Facility at the Electrical Interconnection Point at least eight (8) months prior to the Guaranteed Provisional Acceptance Date (provided that Contractor has made the Facility available as reasonably required to permit such interconnection to have been made by such date).

  • If the Contractor anticipates that Provisional Acceptance will not be achieved by the Guaranteed Provisional Acceptance Date, the Contractor shall promptly provide notice of such anticipated delay to the Owner Lessor, together with a corrective action plan the Contractor intends to adopt in order to achieve Provisional Acceptance as soon after the Guaranteed Provisional Acceptance Date as commercially practicable.

  • Should Owner fail to obtain such permission, then by Change Order pursuant to Sections 19.7 and 19.13, and subject to Section 19.16, the milestone identified in Exhibit 15 as “Ready for Flue Gas to Scrubber” and the Guaranteed Provisional Acceptance Date for such System shall each be extended day-for-day for each day of delay in obtaining such permission.

  • Owner and Contractor hereby acknowledge and agree that the terms, conditions and amounts fixed pursuant to Section 7.2 for Provisional Acceptance Late Completion Payments are reasonable, considering the reduction in value of the Project and the increased costs that it is anticipated Owner will incur in the event of Contractor's failure to achieve at least one of Provisional Acceptance or Final Acceptance of the Facility by the Guaranteed Provisional Acceptance Date.

  • Nothing contained in this Article shall relieve Contractor of its obligation to pay Schedule Liquidated Damages in the event that Provisional Acceptance is not achieved by the Guaranteed Provisional Acceptance Date.

  • The Parties agree that the terms, conditions and amounts fixed as liquidated damages pursuant to Section 8.2.3 for Late Provisional Acceptance Payments are reasonable, considering the actual losses that Owner will incur if Contractor fails to achieve Provisional Acceptance of a System by the Guaranteed Provisional Acceptance Date for such System.


More Definitions of Guaranteed Provisional Acceptance Date

Guaranteed Provisional Acceptance Date means September 25, 2025.
Sample 1Sample 2
Guaranteed Provisional Acceptance Date means the date that is [*] days after the date that Client delivers to Contractor the Notice to Proceed.
Sample 1
Guaranteed Provisional Acceptance Date has the meaning set forth in Section 8.2.2 and shall be the date set forth in the Approved Project Schedule.
Sample 1
Guaranteed Provisional Acceptance Date for each System as set forth in the Approved Project Schedule, subject only to adjustment by Change Order pursuant to Article 19 of this Agreement.
Sample 1
Guaranteed Provisional Acceptance Date means ***, the date which Contractor guarantees that the Project shall achieve Provisional Acceptance, as such date may be extended in accordance with the terms hereof.” 2. The Agreement shall be amended by deleting Section 7.4.3 of Appendix A Scope of Work in its entirety and inserting the following in lieu thereof: “*** 3. The Agreement shall be amended by deleting “Appendix C” of the Agreement in its entirety and inserting “Appendix C” to this Amendment in lieu thereof. 4. The Agreement shall be amended by deleting “Appendix N” of the Agreement in its entirety and inserting “Appendix N” to this Amendment in lieu thereof. 5. This Amendment is executed in connection with, and is deemed to be a part of, the Agreement. Upon the execution of this Amendment, this Amendment shall thereafter automatically become a part of the Agreement. Wherever the terms of this Amendment and the terms of the Agreement are in conflict, the terms of this Amendment shall govern and control. Capitalized terms used herein, unless otherwise defined in this Amendment, shall have the meanings ascribed to them in the Agreement. *** CONFIDENTIAL MATERIAL REDACTED AND SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION. 6. The execution, delivery, and performance of this Amendment has been duly authorized by all requisite corporation action and this Amendment constitutes the legal, valid and binding obligation of FPL and Contractor, enforceable against each Party in accordance with its terms. 7. If any one or more of the provisions of this Amendment should be ruled illegal, wholly or partly invalid or unenforceable by a court or other government body of competent jurisdiction under present or future laws, then: (i) the validity and enforceability of all provisions of this Amendment not ruled to be invalid or unenforceable shall be unaffected and remain in full force and effect; (ii) the effect of the ruling shall be limited to the jurisdiction of the court or other government body making the ruling; (iii) the provision(s) held illegal, wholly or partly invalid or unenforceable shall be deemed amended, and the court or other government body is authorized to reform the provision(s), to the minimum extent necessary to render them valid and enforceable in conformity with the Parties’ intent as manifested herein. 8. The Parties acknowledge and agree that this Amendment may be executed in multiple counterparts, and transmitted via telecopy, each such counterpart (whether transmitted ...
Sample 1
Guaranteed Provisional Acceptance Date means ***, the date which Contractor guarantees that the Project shall achieve Provisional Acceptance, as such date may be extended in accordance with the terms hereof.
Sample 1

Related to Guaranteed Provisional Acceptance Date

  • Final Acceptance Date means, in respect of any Offer, the final date for acceptance of such Offer which, if such Offer is extended prior to becoming unconditional, shall be the final date for acceptance of the extended Offer (but, if such Offer is or becomes unconditional, disregarding any additional or further period during which such Offer is open for acceptance);

  • Guaranteed Commercial Operation Date has the meaning set forth in Section 3.9(c)(i).

  • Conditional Acceptance means a conditional acceptance by the Liquidity Provider of an extension of the Scheduled Termination Date.

  • Acceptance Date has the meaning set forth in Section 2.05(a)(v)(D)(2).

  • Operational Acceptance Tests means the tests specified in the Technical Requirements and Agreed Project Plan to be carried out to ascertain whether the System, or a specified Sub system, is able to attain the functional and performance requirements specified in the Technical Requirements and Agreed Project Plan, in accordance with the provisions of GCC Clause 27.2 (Operational Acceptance Test).

  • Operational Acceptance means the acceptance by the Procuring Entity of the Facilities (or any part of the Facilities where the Contract provides for acceptance of the Facilities in parts), which certifies the Contractor's fulfillment of the Contract in respect of Functional Guarantees of the Facilities (or the relevant part thereof) in accordance with the provisions of GCC Clause 28 (Functional Guarantees) hereof and shall include deemed acceptance in accordance with GCC Clause 25 (Commissioning and Operational Acceptance) hereof.

  • Final Acceptance means final written acceptance of all the Work by the Commissioner, a copy of which shall be sent to the Contractor.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Guaranteed Construction Start Date means the Expected Construction Start Date, as such date may be extended by the Development Cure Period.

  • Final Acceptance Certificate means the certificate that shall be issued by the Engineer to the Contractor upon the satisfactory completion of the contract by the Contractor.

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Additional Accelerated Purchase Date means, with respect to an Additional Accelerated Purchase made pursuant to Section 2(c) hereof, the Business Day (i) that is the Accelerated Purchase Date with respect to the corresponding Accelerated Purchase referred to in clause (i) of the proviso in the second sentence of Section 2(c) hereof and (ii) on which the Investor receives, prior to 1:00 p.m., Eastern time, on such Business Day, a valid Additional Accelerated Purchase Notice for such Additional Accelerated Purchase in accordance with this Agreement.

  • Amortization Commencement Date means the date on which an Amortization Event is deemed to occur pursuant to Section 20 hereof.

  • Fixed wing turbine powered aircraft means an aircraft that:

  • Default under Specified Transaction provisions of Section 5(a)(v) will not apply to Party A and will not apply to Party B.

  • XXXX Acceptance Form means the “Acceptance Form for End User License Agreement (for SAP On Premise indirect sales)” which will be provided by SAP on a deal by deal basis.

  • Acceptance Day shall have the meaning specified in paragraph 2B(5).

  • LCA Test Date has the meaning specified in Section 1.03(e).

  • Acceptance Test is a test of the Features executed by the Customer to prepare the acceptance.

  • Desired Due Date means the desired service activation date as requested by CLEC on a service order.

  • Scheduled Expiration Date is defined in Schedule 1 to the Lease.

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Credit Event Reference Obligation means, with respect to any Payment Date, any Reference Obligation with respect to which a Credit Event has occurred.

  • Contract Effective Date means the date agreed upon by the parties for beginning the period of performance under the contract. In no case shall the effective date precede the date on which the contracting officer or designated higher approval authority signs the document.

  • Acceptance Test Document means a document, which defines procedures for testing the functioning of installed system. The document will be finalized with the contractor within 7 days of issuance of the Letter of Award.

  • CONTRACT END DATE Contract performance shall terminate as of December 31, 2027, with no new obligations being incurred after this date unless the Contract is properly amended, provided that the terms of this Contract and performance expectations and obligations shall survive its termination for the purpose of resolving any claim or dispute, for completing any negotiated terms and warranties, to allow any close out or transition performance, reporting, invoicing or final payments, or during any lapse between amendments. CERTIFICATIONS: Notwithstanding verbal or other representations by the parties, the “Effective Date” of this Contract or Amendment shall be the latest date that this Contract or Amendment has been executed by an authorized signatory of the Contractor, the Department, or a later Contract or Amendment Start Date specified above, subject to any required approvals. The Contractor certifies that they have accessed and reviewed all documents incorporated by reference as electronically published and the Contractor makes all certifications required under the Standard Contract Form Instructions and Contractor Certifications under the pains and penalties of perjury, and further agrees to provide any required documentation upon request to support compliance, and agrees that all terms governing performance of this Contract and doing business in Massachusetts are attached or incorporated by reference herein according to the following hierarchy of document precedence, the applicable Commonwealth Terms and Conditions, this Standard Contract Form, the Standard Contract Form Instructions and Contractor Certifications, the Request for Response (RFR) or other solicitation, the Contractor’s Response (excluding any language stricken by a Department as unacceptable, and additional negotiated terms, provided that additional negotiated terms will take precedence over the relevant terms in the RFR and the Contractor’s Response only if made using the process outlined in 801 CMR 21.07, incorporated herein, provided that any amended RFR or Response terms result in best value, lower costs, or a more cost effective Contract.