a work means the outcome of building or civil engineering works taken as a whole which is sufficient in itself to fulfil an economic or technical function;
job work means any treatment or process undertaken by a person on goods belonging to another registered person and the expression “job worker” shall be construed accordingly;
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Normal Working Hours means 8 a.m. – 5 p.m., Monday – Friday, excluding PBI-observed U.S. holidays, in the time zone where the Equipment or other items are located.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Major Work means any Work to Construct or Maintain the Distribution System that costs more than One Hundred Thousand ($100,000.00) Dollars;
Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Critical Illness means an illness, sickness or disease or corrective measure as specified in Section 6 of this policy document.
Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);
Diagnosis means the definition of the nature of the Client's disorder. When formulating the Diagnosis of Client, CONTRACTOR shall use the diagnostic codes and axes as specified in the most current edition of the DSM published by the American Psychiatric Association. DSM diagnoses will be recorded on all IRIS documents, as appropriate.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Completion of Services means..................................................
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
tidal work means so much of any work authorised by this Order as is on, under or over tidal waters or tidal lands below the level of high water;
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Diagnosis of autism spectrum disorder means medically necessary assessments, evaluations, or tests
The Work means each and every activity required for the successful performance of the services described in Section II, the Terms of Reference.
Temporary Total Disablement means disablement which entirely prevents the Insured Person from attending to their business or occupation.
Defective Work means (a) Work that is unsatisfactory, deficient or damaged, does not conform to the Contract Documents, or does not meet the requirements of any inspection, test or approval, or (b) Work associated with punch list items that the Contractor fails to complete within a reasonable time after issuance of the punch list by the Project Manager.
Mental abnormality or "personality disorder" means a congenital or acquired condition that affects
Diagnosis of autism spectrum disorders means assessments, evaluations, or tests, including the autism diagnostic observation schedule, performed by a licensed physician or a licensed psychologist to diagnose whether an individual has 1 of the autism spectrum disorders.
Persistent Failure means any two (2) or more failures by the Supplier in any rolling period of twelve (12) months to comply with obligations in respect of the Contract Services under the Contract;
Landlord’s Work means the work of constructing the Tenant Improvements.
Work week means a seven (7) consecutive day week that consistently begins and ends on the same days throughout the year; i.e. Sunday through Saturday, Wednesday through Tuesday, Friday through Thursday.
Service Level Failure means a failure to perform the Software Support Services fully in compliance with the Support Service Level Requirements.