Litigation Force Majeure Event definition

Litigation Force Majeure Event means any proceeding before any court, tribunal, or other judicial, adjudicative, or legislative decision-making body, including any administrative appeal, that challenges the validity of any City or SFMTA Regulatory Approval with respect to the Project, including any findings under CEQA, if the pendency of the proceeding is reasonably likely to prevent the Parties from timely entering into the Transaction Documents. Litigation Force Majeure Events exclude any Regulatory Force Majeure Events and any action or proceeding brought by any Developer Affiliate or their Affiliates, any Developer consultant, or any other third party assisted directly or indirectly by Developer.
Sample 1Sample 2Sample 3

Examples of Litigation Force Majeure Event in a sentence

  • In the Litigation Force Majeure Notice, Developer must describe the Litigation Force Majeure Event and provide its good faith estimate of the dates by which Developer will be able to satisfy the Project Schedule, the last of which must be on or before the date that is twenty-four (24) months after the Phase 2 Expiration Date.

  • Developer must deliver a Litigation Force Majeure Notice within thirty (30) days after Developer first learns of the Litigation Force Majeure Event.

  • If Developer cannot satisfy any Project Schedule milestone because of a Litigation Force Majeure Event, then Developer may extend the Exclusive Negotiation Period (a “Litigation Force Majeure Extension”) by notice to City (a “Litigation Force Majeure Notice”).

  • Regulatory Force Majeure Events exclude any Litigation Force Majeure Event and any delay occasioned by the direct or indirect action, inaction, or negligence of Developer, any Affiliate of Developer, or any Developer consultant.

Related to Litigation Force Majeure Event

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Event of Force Majeure means one of the following events:

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;

  • Planned Service Interruption means a Service Interruption that has been scheduled to occur in accordance with schedule 5;

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP:

  • Third Party Terminating Carrier means a Telecommunications Carrier to which traffic is terminated when CLEC originates traffic that is sent through AT&T-TSP’s network, i.e., CLEC is using AT&T-TSP’s Transit Traffic Service.

  • Services Interruption Event means any interruption to a Works caused by; a Force Majeure Event, the Customer’s failure to carry out or perform any obligation required of it under this agreement which in the sole opinion of the Company does or may cause a delay in the Works and any other matter which in the reasonable opinion of the Company will cause an interruption or delay in the performance of the Works;

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Outage has the meaning set forth in the CAISO Tariff.

  • Rectification Period means the period of time set out in Section 4.3 of this RFP during which a Proponent will be permitted to rectify its Proposal to satisfy the mandatory submission requirements of this RFP.

  • Remediation Period has the meaning specified in Section 8.2(a);

  • Uncontrollable Circumstance means any event which:

  • Potential Termination Event means an event which, with the giving of notice and/or the lapse of time, would constitute a Termination Event.