Major Project Change definition

Major Project Change means a (a) delay in the construction of the Project that is reasonably likely to result in a material delay in achieving commercial operations, (b) material increase in the costs of, or liability to, the Project that will not be borne by Seller or otherwise paid, extinguished or fully satisfied as of the Closing Date or (c) to the extent not taken into account in the Base Case Model, fact, event, circumstance, condition or change that has a material adverse effect on the expected generation or operating cost of the Project.
Sample 1Sample 2Sample 3
Major Project Change means a: (a) delay in the construction of the Project that is reasonably likely to result in a material delay in achieving commercial operations of the Project; (b) material increase in the costs of, or liability to, the Project or any Acquired Company that will not be borne by Seller or otherwise paid, extinguished or fully satisfied as of the Closing Date; or (c) to the extent not taken into account in the Base Case Model, any fact, event, circumstance, condition or change that has a material adverse effect on the expected generation from or operating cost of the Project.
Sample 1Sample 2Sample 3
Major Project Change means any change to the Project that changes the amount of Government payment for a Payable Milestone/Deliverable or results in a significant change to the Project results.
Sample 1

Examples of Major Project Change in a sentence

  • The Major Project Change List will be updated on an as-needed basis and will include, but is not limited to: • A description of the scope of the identified challenge necessitating a material change in the Construction Plan • A solution to address the challenge and a rationale for the proposed solution • An update, as necessary, to the milestones and Xxxxx chart to reflect the new approach.

Related to Major Project Change

  • Major project means a project comprising of a series of works, activities or services which is intended, in itself, to accomplish a definite and indivisible task of a precise economic or technical nature, which has clearly identified goals and whose total cost exceeds that which is specified in the Framework Agreement;

  • Major Work means any Work to Construct or Maintain the Distribution System that costs more than One Hundred Thousand ($100,000.00) Dollars;

  • Major renovation means the renovation of a building where:

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • New Project means (a) each facility which is either a new facility, branch or office or an expansion, relocation, remodeling or substantial modernization of an existing facility, branch or office owned by the Borrower or its Subsidiaries which in fact commences operations and (b) each creation (in one or a series of related transactions) of a business unit to the extent such business unit commences operations or each expansion (in one or a series of related transactions) of business into a new market.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Development Site means any parcel or lot on which exists or which is intended for building development other than the following:

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.

  • Project means the goods or Services described in the Signature Document or a Work Order of this Contract.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Project Common Areas as used in this Lease, shall mean the portion of the Project designated as such in the Site Plan. The Project Common Areas shall consist of all parking facilities, entrances and exits, driveways, exterior walkways, first-class landscaped and hardscaped areas which are generally consistent with the quality of landscaped and hardscaped areas of Comparable Buildings in existence as of the date of this Lease, open space areas and plazas on the real property comprising the Project. The term "BUILDING COMMON AREAS," as used in this Lease, shall mean the portions of the Common Areas located within any building in the Project not entirely leased by Tenant, which Building Common Areas shall be reasonably designated as such by Landlord. Notwithstanding the foregoing and subject to (i) Landlord's approval, which approval (as indicated in Section 29.4 below) shall not be unreasonably withheld or delayed, (ii) the CC&R's, and (iii) all terms of this Lease regarding Hazardous Materials, Tenant may install or locate such items as benches, patio tables, bike racks, above-ground generators, security cameras and the like (collectively, "MISCELLANEOUS COMMON AREA ITEMS") at Tenant's sole cost in the Common Areas or on the exterior of the Building, as applicable, provided that Tenant removes such items upon the expiration or earlier termination of this Lease and repairs any damage to the Common Areas or the exterior of the Building (as applicable) resulting from such removal. If Tenant fails to remove any Miscellaneous Common Area Item or to repair any damage resulting from such removal upon the expiration or earlier termination of this Lease, Landlord may do so and may charge Landlord's actual cost thereof to Tenant. The manner in which the Common Areas are maintained and operated shall be in accordance with a standard which is not less than that customarily followed in the operation and maintenance of first class mid-rise office buildings located within the University Towne Center (i.e., the area from two (2) blocks to the North of La Jolla Village Drive to two (2) blocks to the South of La Jolla Village Drive between the I-5 and I-805 freeways), Del Mar, Carmel Valley and Torrey Hills geographical areas, provided that Landlord shall manage, maintain and operate the same in a manner consistent with that of Comparable Buildings, and the use thereof shall be subject to such rules and regulations as Landlord reasonably may make from time to time. As used herein, "COMPARABLE BUILDINGS" shall mean the first class mid-rise office buildings (now existing or subsequently constructed) within the projects located within the University Towne Center, Del Mar, Carmel Valley and Torrey Hills geographical areas and having substantially similar characteristics to the Building pertaining to size, age, accessibility, design, quality, amenities and tenancies. Landlord reserves the right to make alterations or additions to, or to change the location of, elements of the Project and the Common Areas, provided that if any such changes might affect Tenant's use of the Premises (in other than an immaterial manner), Landlord obtains Tenant's prior written approval of any such alterations, additions and changes and such alterations, additions and changes do not unreasonably interfere with Tenant's access to the Premises. Except when and where Tenant's right of access is specifically excluded in this Lease, Tenant shall have the right of access to the Building and the parking facilities twenty-four (24) hours per day, seven (7) days per week during the Lease Term. PEREGRINE SYSTEMS CORPORATE CENTER [Peregrine Systems]

  • Proposed Project SCHEDULE: (edit schedule below as appropriate) Pre-bid Meeting Questions Due Proposals Due Begin Work Programming Phase Permitting Phase Schematic Design Phase Construction Documents Phase Bidding or Negotiation Phase Construction Administration 1-Year Warranty

  • Qualified project means the construction or expansion of any capital project of the Borrower or any of its Restricted Subsidiaries, the aggregate actual or budgeted capital cost of which (in each case, including capital costs expended by the Borrower or any such Restricted Subsidiaries prior to the construction or expansion of such project) exceeds $50,000,000.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Qualified Project Costs means costs paid with respect to the Project that meet each of the following requirements: (i) the costs are properly chargeable to capital account (or would be a so chargeable with a proper election by the Borrower or but for a proper election by the Borrower to deduct such costs) in accordance with general federal income tax principles and in accordance with Section 1.103-8(a)(1) of the Regulations, provided, however, that only such portion of the interest accrued during rehabilitation or construction of the Project (in the case of rehabilitation, with respect to vacated units only) shall be eligible to be a Qualified Project Cost as bears the same ratio to all such interest as the Qualified Project Costs bear to all costs of the acquisition and construction or rehabilitation of the Project; and provided further that interest accruing after the Completion Date (as defined in the Regulatory Agreement) shall not be a Qualified Project Cost; and provided still further that if any portion of the Project is being constructed or rehabilitated by an Affiliate (whether as general contractor or a subcontractor), Qualified Project Costs shall include only (A) the actual out of pocket costs incurred by such affiliate in constructing or rehabilitating the Project (or any portion thereof) and (B) any overhead expenses incurred by such affiliate which are directly attributable to the work performed on the Project, and shall not include, for example, intercompany profits resulting from members of an “affiliated group” (within the meaning of Section 1504 of the Code) participating in the rehabilitation or construction of the Project or payments received by such affiliate due to early completion of the Project (or any portion thereof); (ii) the costs are paid with respect to a qualified residential rental project or projects within the meaning of Section 142(d) of the Code, (iii) the costs are paid after the earlier of 60 days prior to May 20, 2021, being the date on which the Governmental Lender first declared its “official intent” to reimburse costs paid with respect to the Project (within the meaning of Section 1.150-2 of the Regulations) or the date of issue of the Funding Loan, and (iv) if the costs of the acquisition and construction or rehabilitation of the Project were previously paid and are to be reimbursed with proceeds of the Funding Loan such costs were (A) “preliminary expenditures” (within the meaning of Section 1.150-2(f)(2) of the Regulations) with respect to the Project (such as architectural, engineering and soil testing services) incurred before commencement of acquisition and construction or rehabilitation of the Project that do not exceed 20% of the issue price of the Funding Loan (as defined in Section 1.148-1 of the Regulations), or (B) were capital expenditures with respect to the Project that are reimbursed no later than 18 months after the later of the date the expenditure was paid or the date the Project is placed in service (but no later than three years after the expenditures is paid); provided, however, that (w) Costs of Funding shall not be deemed to be Qualified Project Costs;(x) fees, charges or profits (including, without limitation, any Developer Fee) payable to the Borrower or a “related person” (within the meaning of Section 144(a)(3) of the Code) shall not be deemed to be Qualified Project Costs; (y) letter of credit fees and municipal bond insurance premiums which represent a transfer of credit risk shall be allocated between Qualified Project Costs and other costs and expenses to be paid from the proceeds of the Funding Loan; and (z) letter of credit fees and municipal bond insurance premiums which do not represent a transfer of credit risk (including, without limitation, letter of credit fees payable to a “related person” to the Borrower) shall not constitute Qualified Project Costs.

  • Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each, and clearly allocate requested grant funding and match contributions to each.

  • Wind-Down Budget means a budget to be prepared by the Debtors, and reasonably acceptable to the Deerfield Requisite Supporting Noteholders, the Unaffiliated Requisite Supporting Noteholders, and the Committee, which shall be filed with the Court as part of the Plan Supplement, and which may be amended from time to time after entry of the Confirmation Order, subject to the consent of the Oversight Committee, which consent shall not be unreasonably withheld, and which shall estimate the funds necessary to administer the Plan and wind down the Debtors’ affairs, including the costs of holding and liquidating the Estates’ remaining property, objecting to Claims, making the Distributions required by the Plan, prosecuting claims and Causes of Action that may be held by the Estates against third parties that are not released, waived or transferred pursuant to the Plan (including pursuant to Article X) or otherwise, paying Taxes, filing Tax returns, paying professionals’ fees and expenses, paying the fees and expenses of the Oversight Committee, funding payroll and other employee costs, providing for the purchase of errors and omissions insurance and/or other forms of indemnification for the Plan Administrator, and for all such items and other costs of administering the Plan, the Estates and the Liquidating Debtors (other than the Administrative and Priority Claims Reserve, the Disputed Claims Reserve, and the Professional Fee Reserve).

  • Capital Improvement or "Capital Improvement Project" means the acquisition, construction, reconstruction, improvement, planning and equipping of roads and bridges, wastewater treatment facilities, water supply systems, solid waste disposal facilities, and storm water and sanitary collection, storage and treatment facilities of Local Subdivisions, including real property, interests in real property, and facilities and equipment of Local Subdivisions related or incidental thereto.

  • The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Capital Improvement Project means the acquisition, construction, reconstruction, improvement, planning and equipping of roads and bridges, appurtenances to roads and bridges to enhance the safety of animal-drawn vehicles, pedestrians, and bicycles, wastewater treatment facilities, water supply systems, solid waste disposal facilities, and storm water and sanitary collection, storage and treatment facilities including real property, interests in real property, facilities, and equipment related or incidental to those facilities.

  • Project Improvements means site improvements and facilities that are:

  • Major development means an individual “development,” as well as multiple developments that individually or collectively result in:

  • Capital Improvements mean the purchase, renovation, rehabilitation, or construction of permanent land, buildings, structures, equipment and furnishings used directly for or in the Project, and any goods or services for the Project that are purchased and capitalized under GAAP, including any organizational costs and research and development costs incurred in Illinois. Capitalized lease costs for land, buildings, structures or equipment shall be included in “Capital Improvements” only if the lease term, including any extensions or options to extend, equals or exceeds the term of this Agreement, and provided that such lease costs are valued at their present value using the corporate interest rate prevailing at the time the Company filed its Application with the Department.

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Project area budget means a multiyear projection of annual or cumulative