Preliminary Space Plan definition

Preliminary Space Plan shall have the meaning assigned to such term in Section 5.7(a).
Sample 1Sample 2Sample 3
Preliminary Space Plan. Landlord to provide sixteen cents ($0.16) per usable square foot. Said allowance is to pay for Tenant's space planner to design a preliminary drawing of said space.
Sample 1Sample 2
Preliminary Space Plan means a space plan prepared by Architect depicting all improvements and alterations desired by Tenant to be installed or constructed in the Premises. Landlord shall provide to Tenant an allowance up to ONE THOUSAND THIRTY-SIX AND 40/100 DOLLARS ($1,036.40) to reimburse Tenant for the cost of one (1) test-fit plan (the “Test-Fit Allowance”). The Test-Fit Allowance shall be in addition to, and shall not be deducted from, the Construction Allowance.
Sample 1

Examples of Preliminary Space Plan in a sentence

  • If Landlord objects to the Preliminary Space Plan (or any revision thereof), Tenant shall deliver a revised Preliminary Space Plan to Landlord and the procedure will be repeated, if necessary, until a final space plan is approved.

  • Landlord’s approval shall not be unreasonably withheld or delayed and shall be given or withheld, or Landlord shall advise Tenant whether Landlord requires additional information in order to evaluate Tenant’s request, within ten (10) days following Tenant’s delivery to Landlord of the Preliminary Space Plan.

  • Landlord and Tenant shall work with one another reasonably and in good faith to resolve any differences concerning the Preliminary Space Plan and the Final Space Plan (or the Preliminary Drawings or Final Drawings hereafter referenced in Section 5.7(b) immediately below), failing which any disagreements shall be resolved in accordance with Article XII hereof.

  • This is in accordance with the Executive Reporting of Injuries, Diseases and Dangerous Occurrences Regulations 1995.

  • Notwithstanding anything to the contrary contained herein, Landlord agrees that there are no Specialty Alterations on the Preliminary Space Plan.

  • Landlord has caused its architect, Little Architects (“Landlord’s Architect”), to prepare the preliminary space plan, showing the preliminary specifications for the Leasehold Improvements (the “Preliminary Space Plan”), which Preliminary Space Plan has been approved by Landlord and Tenant, a copy of which is attached hereto as Exhibit E-1, but remains subject to further revisions (such Preliminary Space Plan, as finally approved by Landlord and Tenant, being the “Space Plan”).

  • Landlord or Landlord's Architect shall submit the Working Drawings to Tenant for Tenant's review to confirm compliance with the Preliminary Space Plan, and Tenant shall notify Landlord and Landlord's Architect within five (5) business days, after delivery thereof of any requested revisions.

  • The Final Plans will be submitted to Landlord in accordance with the delivery requirements of Section 30.1 of the Lease and via email for signature to confirm that they are consistent with the Preliminary Space Plan.

  • Landlord and Tenant shall work with one another reasonably and in good faith to resolve any differences concerning the Preliminary Space Plan and the Final Space Plan (or the Preliminary Drawings or Final Drawings hereafter referenced in Section 5.9(b)), failing which any disagreements shall be resolved in accordance with Article XII.

  • The Construction Drawings shall indicate the specific requirements of the Premises, outlining in detail interior partitions, floor coverings, a reflected ceiling plan, plumbing fixtures and electrical plans (setting forth the electrical requirements of Tenant), all in conformity with the Preliminary Space Plan.


More Definitions of Preliminary Space Plan

Preliminary Space Plan means a space plan prepared by Architect depicting all improvements and alterations desired by Tenant to be installed or constructed in the Premises. Landlord shall provide to Tenant an allowance up to ONE THOUSAND THIRTY- SIX AND 40/100 DOLLARS ($1,036.40) to reimburse Tenant for the cost of one (1) test-fit plan (the “Test-Fit Allowance”). The Test- Fit Allowance shall be in addition to, and shall not be deducted from, the Construction Allowance.
Sample 1
Preliminary Space Plan means a space plan prepared by the Architect depicting all improvements and alterations to be installed or constructed with respect to the Tenant Improvements.
Sample 1

Related to Preliminary Space Plan

  • Space Plan means the space plan to be prepared by Tenant in accordance with paragraph 2 below and approved by Landlord and Tenant, and showing the general configuration of the Tenant Improvements.

  • Preliminary Work means all work done in the concept and preparatory stages (including non-exhaustively design, artwork, colour matching).

  • Site Plan means a document or map that may be required by a county during a preliminary review preceding the issuance of a building permit to demonstrate that an owner's or developer's proposed development activity meets a land use requirement.

  • Building Drain means that part of the lowest horizontal piping of a drainage system which receives the discharge from soil, waste, and other drainage pipes inside the walls of the building and conveys it to the building sewer, beginning five (5) feet (1.5 meters) outside the inner face of the building wall.

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements in the form of Exhibit D attached hereto.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Building Plans means the general building plans in respect of the Development or in respect of any part or parts of the Development prepared by the Authorized Person and approved by the Building Authority and includes any amendments thereto from time to time approved by the Building Authority;

  • Tenant Improvements Defined in Exhibit B, if any.

  • Preliminary plat means a map showing the salient features of a proposed subdivision submitted to an approving authority for purposes of preliminary consideration.

  • Design-Build Agreement means the design and construction agreement between Project Co and the Design-Builder, a certified copy of which has been delivered by Project Co to the Authority, as amended, supplemented or replaced from time to time in accordance with this Agreement;

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Work area means a room or defined space in a workplace where hazardous chemicals are produced or used, and where employees are present.

  • Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.

  • Building Project means the aggregate combined parcel of land on a portion of which are the improvements of which the Premises form a part, with all the improvements thereon, said improvements being a part of the block and lot for tax purposes which are applicable to the aforesaid land.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Constructional Plan means all appliances or things of whatsoever nature required for the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work.

  • Preliminary Plans means a site plan, architectural floor plans, elevations, outline specifications and a cost estimate for each utility, site development, conversion, and remodeling project. The drawings shall be sufficiently descriptive to accurately convey the location, scope, cost and the nature of the improvement being proposed.

  • Construction Drawings means those drawings containing the technical details associated with the design, construction and installation of the Infrastructure;

  • Construction Completion Certificate means a certificate of the I-Bank to the effect that the construction of the Project is complete.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.