Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of:
(1) any unreasonable delay by Tenant in approving the Plans;
(2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason;
(3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant;
(4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or
(5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.
Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Uncontrollable Circumstance means any act, event or condition that is:
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Developmental delay means that a child has not reached developmental milestones expected for his or her chronological age as measured by qualified professionals using appropriate diagnostic instruments and/or procedures.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and
Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,
Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Service Level Failure means a failure to perform the Software Support Services fully in compliance with the Support Service Level Requirements.
Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation:
(1) acts of God or of the public enemy,
(2) acts of the United States of America in either its sovereign or contractual capacity,
(3) acts of another contractor in the performance of a contract with the Government,
(4) fires,
(5) floods,
(6) epidemics,
(7) quarantine restrictions,
(8) strikes,
(9) freight embargoes,
(10) unusually severe weather, or
(11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.
Allowed Delay has the meaning set forth in Section 2(c)(ii).
Uncontrollable Forces means any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the reasonable control of the nonperforming party. It includes, but is not limited to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, and governmental actions.
Mental abnormality means a congenital or acquired condition affecting the emotional or volitional capacity which predisposes the person to the commission of criminal sexual acts in a degree constituting such person a menace to the health and safety of others.
Service Failure means a failure by the Contractor to provide the Services in accordance with any individual service level described above (measured on a monthly/quarterly/annual basis)
Uncontrollable Force means any cause beyond the control of the Borrower, including: (a) a hurricane, tornado, flood or similar occurrence, landslide, earthquake, fire or other casualty, strike or labor disturbance, freight embargo, act of a public enemy, explosion, war, blockade, terrorist act, insurrection, riot, general arrest or restraint of government and people, civil disturbance or similar occurrence, sabotage, or act of God (provided that the Borrower shall not be required to settle any strike or labor disturbance in which it may be involved) or (b) the order or judgment of any federal, state or local court, administrative agency or governmental officer or body, if it is not also the result of willful or negligent action or a lack of reasonable diligence of the Borrower and the Borrower does not control the administrative agency or governmental officer or body; provided that the diligent contest in good faith of any such order or judgment shall not constitute or be construed as a willful or negligent action or a lack of reasonable diligence of the Borrower.
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Technical Failure means a failure of the court's hardware, software, and/or telecommunications facility which results in the impossibility of submitting a file electronically. Technical failure does not include malfunctioning of the equipment of the person submitting an e-file.
Persistent Failure means any two (2) or more failures by the Supplier in any rolling period of twelve (12) months to comply with obligations in respect of the Contract Services under the Contract;
Mental retardation means a condition of arrested or incomplete development of mind of a person which is specially characterized by sub normality of intelligence;
Force Majeure Event means an event beyond the reasonable control of any party including an outbreak of a serious disease or epidemic, or quarantine or other public health emergencies, fire, flood, earthquake, explosion or other casualty or accident or act of God, or war or other violence, strike, lock-out, labour dispute, acts of any governmental body, war, insurrection, sabotage, embargo, interruption of or delay in transportation, unavailability of or interruption or delay in telecommunications or inability to obtain raw materials, supplies or power.
Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Scheduled Outage means the final outage plan as approved by the RPC as per the provisions of the Grid Code;
Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.
Volume Failure means, with respect to a particular date of determination, the aggregate daily dollar trading volume (as reported on Bloomberg) of the Common Stock on the Principal Market on any Trading Day during the twenty (20) Trading Day period ending on the Trading Day immediately preceding such date of determination (such period, the “Volume Failure Measuring Period”), is less than $2,000,000 (as adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions occurring after the Subscription Date). All such determinations to be appropriately adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions during such Volume Failure Measuring Period.