Scheduled Date of Substantial Completion definition

Scheduled Date of Substantial Completion means the date the Design/Builder has agreed to achieve Substantial Completion of the Project in accordance with the Schedule, as adjusted.
Sample 1Sample 2Sample 3

Examples of Scheduled Date of Substantial Completion in a sentence

  • If Substantial Completion occurs on or prior to the Scheduled Date of Substantial Completion, Owner shall not withhold and the CONTRACTOR shall have no obligation to forego Delay Liquidated Damages under this Section with respect to Substantial Completion of the PROJECT.

  • In the event of Excusable Delay, the Scheduled Date of Substantial Completion shall be adjusted by adding the resulting aggregate number of days of Excusable Delay.

  • In the event that Substantial Completion occurs on or prior to the Scheduled Date of Substantial Completion, the Design-Build Firm shall have no obligation to pay Delay Liquidated Damages under this Section VII.F.

  • Design-Build Firm s’ submission of a recovery schedule that extends beyond the Scheduled Date of Substantial Completion and Scheduled Date of Final Completion due to delay attributable to Design- Build Firm s’ failure to fulfill its obligations under this Agreement shall constitute Design- Build Firm s’ agreement that Design-Build Firm shall be liable for Delay Liquidated Damages in accordance with Section VII.G, below.

  • The Design-Build Firm shall achieve Substantial Completion by the applicable Scheduled Date of Substantial Completion to be established for NEOC and NESC, as shown in the Project Schedule (Exhibit 6).

  • In the event that Substantial Completion occurs subsequent to the Scheduled Date of Substantial Completion, the Design-Build Firm shall pay Owner Delay Liquidated Damages in accordance with this subsection for each Day that the Substantial Completion is delayed beyond the Scheduled Date of Substantial Completion and continuing until the earlier of (i) the actual achievement of the Substantial Completion, or (ii) termination of this Agreement for default.

  • In such event, Delay Liquidated Damages shall accrue from the Scheduled Date of Substantial Completion, as the same may be extended.

  • The Construction Schedule is a subset of the Project Schedule, and therefore some changes to the Construction Schedule and/or Scheduled Date of Substantial Completion may necessitate changes to the Project Schedule.

  • The Scheduled Date of Substantial Completion 808 shall in no event be later than December 31, 2021 unless extended in accordance with the terms 809 of this Agreement or as otherwise agreed by the Parties (the “Long Stop Date”).

  • County and Developer agree that there shall be no Delay Liquidated Damages if the date of Substantial Completion of the Project Work for the Enabling Projects or the CVB Office occurs after the Scheduled Date of Substantial Completion as shown in the Master Project Schedule or any Project Construction Schedule for such Projects or portions thereof.

Related to Scheduled Date of Substantial Completion

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.

  • Lease Commencement Date means the Closing Date. The “Lease Expiration Date” shall mean the later of (i) the date of the final payment in full of the French Advances and (ii) the Vehicle Lease Expiration Date for the last Lease Vehicle leased by the Lessee hereunder. The “Term” of this Agreement shall mean the period commencing on the Lease Commencement Date and ending on the Lease Expiration Date.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Certificate of Substantial Performance means a certificate issued by the NCC when the Work reaches Substantial Performance;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Billing Commencement Date means the earlier of: