System Completion Date definition

System Completion Date has the meaning given such term in Section 3.2.
Sample 1Sample 2Sample 3
System Completion Date means 14 December 1998
Sample 1Sample 2
System Completion Date means the delivery date established for the System as set forth in the Implementation Plan and Schedule mutually agreed to between the Parties as set forth in Section2.2 and Exhibit “D” attached hereto.
Sample 1

Examples of System Completion Date in a sentence

  • Notwithstanding the foregoing, the waiver of the Pressure Requirements will not otherwise relieve the Parties of the obligations under this Agreement, including, without limitation, the obligation to meet the Gathering System Completion Date or the Milestone Completion Dates.

  • The term of this Agreement shall commence on the Effective Date and shall terminate on the twenty-fifth (25th) anniversary of the System Completion Date (the “Term”); provided, however, that if Gatherer has received no Shipper’s Oil from Shipper for any period of twelve (12) consecutive months, Gatherer may terminate this Agreement upon written notice to Shipper.

  • If the System Completion Date has not occurred on or before March 31, 2016, Shipper may terminate this Agreement.

  • Such payment shall be without prejudice to the Vendor’s obligation to complete the Services as soon after the Targeted System Completion Date as possible.

  • Within thirty (30) Days of the System Completion Date, Shipper shall commence and thereafter continue on an uninterrupted basis (except for interruptions caused by Force Majeure, Permissible Interruptions or Gatherer) delivery of Shipper’s Oil into the Base Gathering System.

  • Gatherer shall utilize commercially reasonable efforts to complete construction of the Magnolia Gathering System by or before December 31, 2010 (the “Gathering System Completion Date”) provided that no later than June 30, 2010, all Receipt Points have been designated as per Section 5.6. Gatherer shall deliver to Shipper written notice of the Gathering System Completion Date within three (3) Business Days after the occurrence thereof.

  • The Parties acknowledge and agree that Shipper’s successful development of the Committed Area depends upon the timely completion of the Olympia Gathering System In addition, it may be difficult to calculate the amount of damages or Losses Shipper incurs in the event that the Olympia Gathering System is not completed by the Gathering System Completion Date and in a manner that complies with the Initial Build Conditions.

  • Effective on the Gathering System Completion Date, the Initial Guaranty Amount shall become Fifty Million U.S. Dollars (U.S. $50,000,000.00) until this Guaranty terminates.

  • In such case, the Integration Services applicable to such Product will be deemed complete upon Customer’s Beneficial Use of the Product (“Product Completion Date”), which may occur before the System Completion Date.

  • HealthGate shall present to the Publishers a disaster recovery plan prior to the System Completion Date.


More Definitions of System Completion Date

System Completion Date means March 1, 2016. US-DOCS\70393108.5
Sample 1
System Completion Date means the date that System Completion has been achieved; “System Outage” means an Outage that is not an Equipment-Only Outage;
Sample 1
System Completion Date means the delivery date established for each System as set forth in the Implementation Plan and Schedule mutually agreed to between the Parties as set forth in Section 2.2.
Sample 1
System Completion Date means the date that System Completion has been achieved;
Sample 1

Related to System Completion Date

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion Date means the date on which Final Completion occurs.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Billing Commencement Date means the earlier of:

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Service Date or "SD" means the date service is made available to the End User Customer. This also is referred to as the "Due Date."

  • Start Date for Term Calculation Purposes Only: Regardless of actual award/effective date of Contract, for Agreement “term” calculation purposes only, the Agreement “start date” is the last day of the month that Award Notifications are anticipated as published in the Solicitation. Example: If the anticipated award date published in the Solicitation is August 27, 2020 but extended negotiations delay award until September 24, 2020 the end date of the resulting initial “two-year” term Agreement, (which is subject to an extension(s)) will still be August 31, 2022 in this example

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Vesting Commencement Date means the Grant Date or such other date selected by the Committee as the date from which an Award begins to vest.

  • Work Day means any day that an Employee is regularly scheduled to work and for which the Employee receives payment from the Employer.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Policy Commencement Date means the date of commencement of the Policy as specified in the Schedule.

  • Pay Out Commencement Date means the date on which a Trust Pay Out Event is deemed to occur pursuant to Section 9.01 of the Agreement or a Series 2001-D Pay Out Event is deemed to occur pursuant to Section 7 hereof.

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • DAY WORK means on item of work requiring the employment of labour with or without materials as the case may be, which, in the opinion of the Senior Engineer /Civil-in-charge, is not capable of being evaluated by the accepted methods of measurement or assessment and is paid for on the basis of the actual labour and materials utilised on the particular item of work referred to.

  • Benefit Commencement Date means, for any Participant or beneficiary, the date as of which the first benefit payment, including a single sum, from the Participant’s Account is due, other than pursuant to a withdrawal under Article VIII.

  • Continuous Shift Work means work done by Employees where the hours of work are regularly rotated in accordance with a shift roster covering a 24 hour per day operation over a 7 day week.