Survey Area means the area of land or waters the subject of a Survey, or proposed to be the subject of a Survey.
Work Site means the site where the Work is being performed.
Professional land surveyor means a professional land surveyor licensed under ch. 443.
Project Architect means the professional architect or engineer employed by the Owner as architect or engineer of record for the Project and its consultants.
Survey shall have the meaning set forth in Section 4.1.
Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.
Landscape architect means a person who holds a license to practice landscape architecture in the state of California Business and Professions Code, Section 5615.
Work package means a major sub-division of the proposed project.
Design-build team means an entity that consists of:
Land surveyor means a person who by reason of knowledge of
Design-Build Firm means a partnership, corporation or other legal entity that:
Work week means a seven (7) consecutive day week that consistently begins and ends on the same days throughout the year; i.e. Sunday through Saturday, Wednesday through Tuesday, Friday through Thursday.
Work area means a room or defined space in a workplace where hazardous chemicals are produced or used, and where employees are present.
Architect/Engineer means the person designated by the Commissioner to provide the Contract drawings and Detailed Specifications for the Work you are to perform.
Building Inspector means a person licensed to carry out completed residential building inspections under the Queensland Building and Construction Commission Regulations 2003;
Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.
Installation inspector means a person who, by reason of his knowledge of the physical sciences and the principles of engineering, acquired by a professional education and related practical experience, is qualified to supervise the installation of tank systems.
Standard Specifications means a compilation in book form of specifica- tions approved for general application and repetitive use;
Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.
Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.
Work crew means a program of partial confinement
Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.
Work Day means any day that an Employee is regularly scheduled to work and for which the Employee receives payment from the Employer.
Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.
building society means a building society within the meaning of the Building Societies Act 1986;
The Site, where applicable, means the designated project place(s) named in the bidding document.