03C Changes in Unit Cost of Work Sample Clauses

03C Changes in Unit Cost of Work. If an ordered change in the IFC Plans or Specifications materially changes the unit cost to perform the work of a TCP Item from that on which Contractor based the TCP Item price, and if the change increases or decreases the actual unit cost of the changed item as compared to the actual or estimated actual unit cost of performing the work of that item in accordance with the Conformed plans and specifications , in the absence of an executed contract change order specifying the compensation payable, an adjustment in compensation therefore will be made in accordance with the following. The basis of the adjustment in compensation will be the difference between the actual unit cost to perform the work of that item or portion thereof involved in the change as originally planned and the actual unit cost of performing the work of the item or portion thereof involved in the change, as changed. Actual unit costs will be determined by the Engineer in the same manner as if the work were to be paid for on a force account basis as provided in Section 9- 1.03, "Scope of Payment;" or the adjustment will be as agreed to by Contractor and the Engineer. The adjustment will apply only to the portion of the work of the item actually changed in character. At the option of the Engineer, the work of the item or portion of item which is changed in character will be paid for by force account as provided in Section 9-1.03. If the compensation for an item of work is adjusted under this Section 4-1.03C, the costs recognized in determining that adjustment shall be excluded from consideration in making an adjustment for that item of work under the provisions in Section 4-1.03B, "Increased or Decreased Quantities." Failure of the Engineer to recognize a change in character of the work at the time the approved contract change order is issued shall in not be construed as relieving Contractor of the duty and responsibility of filing a written protest within the 15 day limit as provided in Section 4-1.03A, "Procedure and Protest."
Sample 1
AutoNDA by SimpleDocs

Related to 03C Changes in Unit Cost of Work

  • Cost of Work The Cost of Work will be adjusted and finalized as part of the Contract Sum in the GMP. The budget for the Cost of Work shall not exceed Five Million Three Hundred Six Thousand Eight Hundred Five and No/100 Dollars ($5,306,805.00).

  • Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.

  • Contract Term Adjustment “Contract Term Adjustment” means adjustment only as provided for in the three circumstances described in this Subsection. Under these circumstances, the contract term shall be adjusted in writing to include additional calendar days in one or more Normal Operating Seasons equal to the actual time lost, except as limited by paragraph (b) in this Subsection. To qualify for such adjustment, Purchaser shall give written notice of the lost time not later than 30 days after end of Normal Operating Season in which time was lost and at least 10 days before Termination Date. Contracting Officer shall make prompt written acknowledgment of such notice, indicating concurrence with the number of days in the notice or the number of days Forest Service considers as qualifying for the adjustment. Lost portions of days shall be disregarded in computing time lost. The three circumstances qualifying for a Contract Term Adjustment are:

  • Benchmarks for Measuring Accessibility For the purposes of this Agreement, the accessibility of online content and functionality will be measured according to the W3C’s Web Content Accessibility Guidelines (WCAG) 2.0 Level AA and the Web Accessibility Initiative Accessible Rich Internet Applications Suite (WAI-ARIA) 1.0 for web content, which are incorporated by reference. Adherence to these accessible technology standards is one way to ensure compliance with the College’s underlying legal obligations to ensure that people with disabilities are able to acquire the same information, engage in the same interactions, and enjoy the same benefits and services within the same timeframe as their nondisabled peers, with substantially equivalent ease of use; that they are not excluded from participation in, denied the benefits of, or otherwise subjected to discrimination in any College programs, services, and activities delivered online, as required by Section 504 and the ADA and their implementing regulations; and that they receive effective communication of the College’s programs, services, and activities delivered online.

  • Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones:

  • For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

  • Purchase Order Flip via Ariba Network (AN) The online process allows suppliers to submit invoices via the AN for catalog and non- catalog goods and services. Contractors have the ability to create an invoice directly from their Inbox in their AN account by simply “flipping” the purchase order into an invoice. This option does not require any special software or technical capabilities. For the purposes of this section, the Contractor warrants and represents that it is authorized and empowered to and hereby grants the State and the third-party provider of MFMP the right and license to use, reproduce, transmit, distribute, and publicly display within the system the information outlined above. In addition, the Contractor warrants and represents that it is authorized and empowered to and hereby grants the State and the third-party provider the right and license to reproduce and display within the system the Contractor’s trademarks, system marks, logos, trade dress, or other branding designation that identifies the products made available by the Contractor under the Contract.

  • Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.