A/E’s Submittal Review Sample Clauses

A/E’s Submittal Review. The A/E shall review submittals for conformity with design intent within 14 days of receiving them or in accordance with the approved submittal schedule, or other period as mutually agreed by the A/E and the Contractor. The A/E’s review of submittals is to determine if the items covered by the submittals will, after installation and incorporation into the Work, conform to the Contract Documents and be compatible with the design concept of the Project as a functioning whole. 6.20.5.1 The Contractor shall make corrections required by the A/E and resubmit the required number of corrected copies of submittals until approved, which resubmission shall be acted upon by the A/E within 14 days of receiving them, or other period as is mutually agreed by the A/E and the Contractor. 6.20.5.2 When resubmitting corrected submittals, the Contractor shall direct the A/E’s attention to revisions made by noting revisions on the resubmittal. 6.20.5.3 The Contractor shall pay all reasonable costs of the A/E, the Owner, and the Contracting Authority for attendant delay, interference, hindrance or disruption of the Project due to excessive resubmittals without fault of the A/E, the Owner, or the Contracting Authority. Resubmittals in excess of 2 without fault of the A/E, the Owner, or the Contracting Authority may be determined excessive by the Contracting Authority. 6.20.5.4 The A/E may hold Samples and other submittals used to coordinate finishes, colors, patterns, textures, or other characteristics until submittals for adjacent materials are available. The A/E shall issue a written notice to the Contractor stating that the submittal is being held, within 7 days of receiving it. 6.20.5.5 If coordinating submittals are not received within the period required for action on previously received submittals that are held in accordance with Section 6.20.5.46.20.5.4, review of the previously received submittals shallmay be delayed. 6.20.5.6 The A/E’s review shall not extend to means, methods, manners, techniques, sequences, noror procedures of construction, or to safety precautions or incident programs. 6.20.5.7 The review and approval of a separate item shall not indicate approval of the assembly in which the item functions.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs

Related to A/E’s Submittal Review

  • Program Review The State ECEAP Office will conduct a review of each contractor’s compliance with the ECEAP Contract and ECEAP Performance Standards every four years. The review will involve ECEAP staff and parents. After the Program Review, the State ECEAP Office will provide the contractor with a Program Review report. The contractor must submit an ECEAP Corrective Action Plan for non-compliance with ECEAP Performance Standards. The Plan must be approved by the State ECEAP Office.

  • Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.

  • AUDIT REVIEW PROCEDURES Any dispute concerning a question of fact arising under an interim or post audit of this AGREEMENT that is not disposed of by agreement, shall be reviewed by ALAMEDA CTC’s Deputy Executive Director of Finance and Administration. Not later than thirty (30) calendar days after issuance of the final audit report, CONSULTANT may request a review by ALAMEDA CTC’s Deputy Executive Director of Finance and Administration of unresolved audit issues. The request for review will be submitted in writing. Neither the pendency of a dispute nor its consideration by ALAMEDA CTC will excuse CONSULTANT from full and timely performance, in accordance with the terms of this AGREEMENT. CONSULTANT and subconsultants’ contracts, including cost proposals and ICRs, may be subject to audits or reviews such as, but not limited to, an AGREEMENT Audit, an Incurred Cost Audit, an ICR Audit, or a certified public accountant (“CPA”) ICR Audit Workpaper Review. If selected for audit or review, the AGREEMENT, cost proposal and ICR and related workpapers, if applicable, will be reviewed to verify compliance with 48 CFR, Chapter 1, Part 31 and other related laws and regulations. In the instances of a CPA ICR Audit Workpaper Review it is CONSULTANT’s responsibility to ensure federal, state, or local government officials are allowed full access to the CPA’s workpapers including making copies as necessary. The AGREEMENT, cost proposal, and ICR shall be adjusted by CONSULTANT and approved by ALAMEDA CTC to conform to the audit or review recommendations. CONSULTANT agrees that individual terms of costs identified in the audit report shall be incorporated into the contract by this reference if directed by ALAMEDA CTC at its sole discretion. Refusal by CONSULTANT to incorporate audit or review recommendations, or to ensure that the federal, state, or local governments have access to CPA workpapers, will be considered a breach of contract terms and cause for termination of the AGREEMENT and disallowance of prior reimbursed costs.

  • Log Reviews All systems processing and/or storing PHI COUNTY discloses to 11 CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY 12 must have a routine procedure in place to review system logs for unauthorized access.

  • Project Review A. Programmatic Allowances 1. If FEMA determines that the entire scope of an Undertaking conforms to one or more allowances in Appendix B of this Agreement, with determinations for Tier II Allowances being made by SOI-qualified staff, FEMA shall complete the Section 106 review process by documenting this determination in the project file, without SHPO review or notification. 2. If the Undertaking involves a National Historic Landmark (NHL), FEMA shall notify the SHPO, participating Tribe(s), and the NPS NHL Program Manager of the NPS Midwest Regional Office that the Undertaking conforms to one or more allowances. FEMA shall provide information about the proposed scope of work for the Undertaking and the allowance(s) enabling FEMA’s determination. 3. If FEMA determines any portion of an Undertaking’s scope of work does not conform to one or more allowances listed in Appendix B, FEMA shall conduct expedited or standard Section 106 review, as appropriate, for the entire Undertaking in accordance with Stipulation II.B, Expedited Review for Emergency Undertakings, or Stipulation II.C, Standard Project Review. 4. Allowances may be revised and new allowances may be added to this Agreement in accordance with Stipulation IV.A.3, Amendments. B. Expedited Review for Emergency Undertakings

  • Independent Review Contractor shall provide the Secretary of ADS/CIO an independent expert review of any Agency recommendation for any information technology activity when its total cost is $1,000,000.00 or greater or when CIO requires one. The State has identified two sub-categories for Independent Reviews, Standard and Complex. The State will identify in the SOW RFP the sub-category they are seeking. State shall not consider bids greater than the maximum value indicated below for this category. Standard Independent Review $25,000 Maximum Complex Independent Review $50,000 Maximum Per Vermont statute 3 V.S.A. 2222, The Secretary of Administration shall obtain independent expert review of any recommendation for any information technology initiated after July 1, 1996, as information technology activity is defined by subdivision (a) (10), when its total cost is $1,000,000 or greater or when required by the State Chief Information Officer. Documentation of this independent review shall be included when plans are submitted for review pursuant to subdivisions (a)(9) and (10) of this section. The independent review shall include: • An acquisition cost assessment • A technology architecture review • An implementation plan assessment • A cost analysis and model for benefit analysis • A procurement negotiation advisory services contract • An impact analysis on net operating costs for the agency carrying out the activity In addition, from time to time special reviews of the advisability and feasibility of certain types of IT strategies may be required. Following are Requirements and Capabilities for this Service: • Identify acquisition and lifecycle costs; • Assess wide area network (WAN) and/or local area network (LAN) impact; • Assess risks and/or review technical risk assessments of an IT project including security, data classification(s), subsystem designs, architectures, and computer systems in terms of their impact on costs, benefits, schedule and technical performance; • Assess, evaluate and critically review implementation plans, e.g.: • Adequacy of support for conversion and implementation activities • Adequacy of department and partner staff to provide Project Management • Adequacy of planned testing procedures • Acceptance/readiness of staff • Schedule soundness • Adequacy of training pre and post project • Assess proposed technical architecture to validate conformance to the State’s “strategic direction.” • Insure system use toolsets and strategies are consistent with State Chief Information Officer (CIO) policies, including security and digital records management; • Assess the architecture of the proposed hardware and software with regard to security and systems integration with other applications within the Department, and within the Agency, and existing or planned Enterprise Applications; • Perform cost and schedule risk assessments to support various alternatives to meet mission need, recommend alternative courses of action when one or more interdependent segment(s) or phase(s) experience a delay, and recommend opportunities for new technology insertions; • Assess the architecture of the proposed hardware and software with regard to the state of the art in this technology. • Assess a project’s backup/recovery strategy and the project’s disaster recovery plans for adequacy and conformance to State policy. • Evaluate the ability of a proposed solution to meet the needs for which the solution has been proposed, define the ability of the operational and user staff to integrate this solution into their work.

  • Post Review With respect to each contract not governed by paragraph 2 of this Part, the procedures set forth in paragraph 4 of Appendix 1 to the Guidelines shall apply.

  • Claims Review Methodology ‌‌ a. C laims Review Population. A description of the Population subject‌‌ to the Quarterly Claims Review.

  • Peer Review Dental Group, after consultation with the Joint ----------- Operations Committee, shall implement, regularly review, modify as necessary or appropriate and obtain the commitment of Providers to actively participate in peer review procedures for Providers. Dental Group shall assist Manager in the production of periodic reports describing the results of such procedures. Dental Group shall provide Manager with prompt notice of any information that raises a reasonable risk to the health and safety of Group Patients or Beneficiaries. In any event, after consultation with the Joint Operations Committee, Dental Group shall take such action as may be reasonably warranted under the facts and circumstances.

  • SITE-BASED DECISION MAKING A. The District shall provide the training and staff development to support accountability/site- based decision-making activities. Teachers shall be given release time to attend these programs. B. Participation on the SAC shall not serve as a basis for the evaluation of any teacher. C. A minimum of three (3) to a maximum of five (5) teachers from each school shall serve on their school’s budget advisory committee formed for the purpose of making recommendations on the school’s general fund budget. Teacher members shall be elected by the faculty. Minutes from such meetings may be requested by the faculty and may be posted on the CTA bulletin board at the school by the Association Representative.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!