Acceptance Management Sample Clauses

Acceptance Management. This section defines the formal Acceptance process that will be followed throughout the service. Acceptance of a work request by Customer indicates that WorkForce has provided the service according to the accepted requirements and design documented by written approval of Customer Authorized MSS contact. Acceptance of services under this SOW is the responsibility of Xxxxxxxx’s Authorized MSS Contact. Completed services will be communicated by WorkForce in monthly Status Reports. If Customer reasonably determines that a service is incomplete, or otherwise materially unacceptable, Customer will document all deficiencies and communicate them to WorkForce within thirty (30) calendar days of receipt of the monthly Status Report. WorkForce will address all the deficiencies documented, or mutually agree with Customer to alternative actions.
Sample 1
AutoNDA by SimpleDocs
Acceptance Management. Managing the review and acceptance process for eFare vendor deliverables including documentation deliverables such as project plans, schedules, and configuration specifications. • Manage, and, if required, perform the acceptance activities for eFare equipment and eFare equipment installations. • Manage to resolution eFare delivery compliance and acceptance issues with the eFare vendor.
Sample 1
Acceptance Management. In an effort to avoid schedule delays stemming from delayed approvals of dependent tasks, MERIDIAN and CLIENT will mutually define a reasonable acceptance review period that does not jeopardize the project duration as outlined within the project management support period. Delays in accepting project deliverables could result in a schedule slippage equaling as much as one day for every day acceptance review is delayed. Below are the methods used to verify and validate each of the defined deliverable(s).
Sample 1

Related to Acceptance Management

  • Contract Management To ensure full performance of the Contract and compliance with applicable law, the System Agency may take actions including: a. Suspending all or part of the Contract; b. Requiring the Grantee to take specific corrective actions in order to remain in compliance with term of the Contract; c. Recouping payments made to the Grantee found to be in error; d. Suspending, limiting, or placing conditions on the continued performance of the Project; e. Imposing any other remedies authorized under this Contract; and f. Imposing any other remedies, sanctions or penalties permitted by federal or state statute, law, regulation, or rule.

  • Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity 1.1.02 Identify at least one individual to act as the program contact in the following areas: 1. Immunization Program Manager;

  • Account Management 15.1 The Contractor is required to provide a dedicated Strategic Account Manager who will be the main point of contact for the Authority. The Strategic Account Manager will:  Attend quarterly, or as otherwise agreed, review meetings with the Authority, in person at the Authority’s premises or other locations as determined by the Authority  Attend regular catch-up meetings with the Authority, in person or by telephone/videoconference  Resolve any on-going operational issues which have not been resolved by the Contractor or Account Manager(s) and therefore require escalation  Ensure that the costs involved in delivering the Framework are as low as possible, whilst always meeting the required standards of service and quality. 15.2 The Contractor is also required to provide a dedicated Account Manager for every Framework Public Body using the Framework, if required by the Framework Public Body. The service to be provided will be agreed with each Framework Public Body and may include:  regular review meetings, which may be in person at the Framework Public Bodies’ premises, by video-conference, webinar or telephone  Regular catch-up meetings/telephone calls to discuss current and on-going issues  Work with the Framework Public Bodies Contract Manager to resolve any on-going operational issues  Work with the Framework Public Body ’s Contract Manager to pro-actively introduce initiatives to:  Create efficiencies in processes  Improve the environmental performance of the contract. 15.3 It is expected that end users will contact the Contractor in the first instance to resolve any operational issues. The Account Manager will act as a point of escalation to be contacted either by end users or by the Framework Public Body’s Contract Manager should there be issues that the Contractor needs to resolve. 15.4 Further details of the roles and responsibilities of the Contractor, Authority and Framework Public Bodies are provided in Schedule 4 – Management Arrangements

  • Performance Management 17.1 The Contractor will appoint a suitable Account Manager to liaise with the Authority’s Strategic Contract Manager. Any/all changes to the terms and conditions of the Agreement will be agreed in writing between the Authority’s Strategic Contract Manager and the Contractor’s appointed representative. 17.2 The Contractor will ensure that there will be dedicated resources to enable the smooth running of the Framework Agreement and a clear plan of contacts at various levels within the Contractor's organisation. Framework Public Bodies may look to migrate to this Framework Agreement as and when their current contractual arrangements expire. The Contractor will where necessary assign additional personnel to this Framework Agreement to ensure agreed service levels are maintained and to ensure a consistent level of service is delivered to all Framework Public Bodies. 17.3 In addition to annual meetings with the Authority's Strategic Contract Manager, the Contractor is expected to develop relationships with nominated individuals within each of the Framework Public Bodies to ensure that the level of service provided on a local basis is satisfactory. Where specific problems are identified locally, the Contractor will attempt to resolve such problems with the nominated individual within that organisation. The Authority's Strategic Contract Manager will liaise (or meet as appropriate) regularly with the Framework Public Bodies' Contract Manager, and where common problems are identified, it will be the responsibility of the Contractor to liaise with the Authority's Strategic Contract Manager to agree a satisfactory course of action. Where the Contractor becomes aware of a trend that would have a negative effect on one or more of the Framework Public Bodies, they should immediately notify the Authority's Strategic Contract Manager to discuss corrective action. 17.4 Regular meetings, frequency to be advised by Framework Public Body, will be held between the Framework Public Bodies' Contract Manager and the Contractor's representative to review the performance of their Call-Off Contract(s) under this Framework Agreement against the agreed service levels as measured through Key Performance Indicators (KPIs). Reports will be provided by the Contractor to the Framework Public Bodies' Contract Manager at least 14 days prior to the these meetings. 17.5 Performance review meetings will also be held annually, between the Authority's Strategic Contract Manager and the Contractor's representative to review the performance of the Framework Agreement against the agreed service levels as measured through Key Performance Indicators. A summary of the quarterly reports will be provided by the Contractor at least 14 days prior to these meetings. 17.6 The Authority will gather the outputs from contract management to review under the areas detailed in the table below. Provision of management reports 90% to be submitted within 10 working days of the month end Report any incident affecting the delivery of the Service(s) to the Framework Public Body 100% to be reported in writing to FPB within 24 hours of the incident being reported by telephone/email Prompt payment of sub-contractors and/or consortia members (if applicable). Maximum of 30 from receipt of payment from Framework Public Bodies, 10 days target 100% within 30 days

  • Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout

  • Case Management Prompt resolution of any dispute is important to both parties; and the parties agree that the arbitration of any dispute shall be conducted expeditiously. The arbitrators are instructed and directed to assume case management initiative and control over the arbitration process (including scheduling of events, pre-hearing discovery and activities, and the conduct of the hearing), in order to complete the arbitration as expeditiously as is reasonably practical for obtaining a just resolution of the dispute.

  • Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:

  • Change Management BellSouth provides a collaborative process for change management of the electronic interfaces through the Change Control Process (CCP). Guidelines for this process are set forth in the CCP document as amended from time to time during this Agreement. The CCP document may be accessed via the Internet at xxxx://xxx.xxxxxxxxxxxxxxx.xxxxxxxxx.xxx.

  • Service Management Effective support of in-scope services is a result of maintaining consistent service levels. The following sections provide relevant details on service availability, monitoring of in-scope services and related components.

  • Project Management Plan 3.2.1 Developer is responsible for all quality assurance and quality control activities necessary to manage the Work, including the Utility Adjustment Work. Developer shall undertake all aspects of quality assurance and quality control for the Project and Work in accordance with the approved Project Management Plan, Good Industry Practice and applicable Law. 3.2.2 Developer shall develop the Project Management Plan and its component parts, plans and other documentation in accordance with the requirements set forth in Section 1.5.2.5

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!