Acceptance of District Funded Public Improvements by District Sample Clauses

Acceptance of District Funded Public Improvements by District. The District shall accept District Funded Public Improvements only upon written certification and warranty by the Builder conveying such improvements and delivered to the City’s Director, Department of Development Services, as follows: (i) The District Funded Public Improvements have been inspected, approved for dedication to, and will be accepted (a) the City, as evidenced by the City’s issuance of a “Letter of Completion” for the applicable portion of the District Funded Public Improvements or (b) a Participating Agency, as evidenced by such documentation described in the separate agreements entered into between a Builder and the Participating Agency; and (ii) The costs of constructing the District Funded Public Improvements actually have been incurred by a Builder, together with documentation of those costs reasonably acceptable to the District. The actual costs of constructing the District Funded Public Improvements may include any of the following, which are in addition to any other categories of costs otherwise acceptable to the governing body of the District (the “District Board”): (a) Builder’s actual, reasonable cost of constructing the District Funded Public Improvements, including labor, material and equipment costs, (b) Builder’s actual, reasonable cost of preparing the Plans for the District Funded Public Improvements, (c) Builder’s actual, reasonable cost of environmental evaluations required for the District Funded Public Improvements, (d) the amount of the fees actually paid by Builder to governmental agencies in order to obtain permits, licenses or other necessary governmental approvals for the District Funded Public Improvements, (e) Builder’s actual, reasonable cost for professional services directly related to the construction of the District Funded Public Improvements, including engineering, inspection, construction staking, materials testing and similar professional services, (f) the costs incurred by Builder for construction management and supervision, (g) Builder’s actual, reasonable cost of any title insurance required for the District Funded Public Improvements, (h) Builder’s costs for financing calculated by applying 5% interest to the total amount of each construction loan draw from the date of the draw to the date the District accepts the applicable District Funded Public Improvements, and (i) Builder’s actual, reasonable cost of any real property or interest therein acquired, which real property or interest therein is necessar...
Sample 1
AutoNDA by SimpleDocs

Related to Acceptance of District Funded Public Improvements by District

  • Materiality Of Application To Rent All representations made by Xxxxxx(s) on the Application to Rent (or like-titled document) are material to the grant of this Lease, and the Lease is granted only on condition of the truthfulness and accuracy of said representations. If a failure to disclose or lack of truthfulness is discovered on said Application, Landlord may deem Tenant to be in breach of this Lease.

  • Procedure for Notification and Defense of Claim (a) To obtain indemnification under this Agreement, Indemnitee shall submit to the Company a written request therefor specifying the basis for the claim, the amounts for which Indemnitee is seeking payment under this Agreement, and all documentation related thereto as reasonably requested by the Company. (b) In the event that the Company shall be obligated hereunder to provide indemnification for or make any advancement of Expenses with respect to any Proceeding, the Company shall be entitled to assume the defense of such Proceeding, or any claim, issue or matter therein, with counsel approved by Indemnitee (which approval shall not be unreasonably withheld or delayed) upon the delivery to Indemnitee of written notice of the Company’s election to do so. After delivery of such notice, approval of such counsel by Indemnitee and the retention of such counsel by the Company, the Company will not be liable to Indemnitee under this Agreement for any fees or expenses of separate counsel subsequently employed by or on behalf of Indemnitee with respect to the same Proceeding; provided that (i) Indemnitee shall have the right to employ separate counsel in any such Proceeding at Indemnitee’s expense and (ii) if (A) the employment of separate counsel by Indemnitee has been previously authorized by the Company, (B) Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Company and Indemnitee in the conduct of such defense, or (C) the Company shall not continue to retain such counsel to defend such Proceeding, then the fees and expenses actually and reasonably incurred by Indemnitee with respect to his or her separate counsel shall be Expenses hereunder. (c) In the event that the Company does not assume the defense in a Proceeding pursuant to paragraph (b) above, then the Company will be entitled to participate in the Proceeding at its own expense. (d) The Company shall not be liable to indemnify Indemnitee under this Agreement for any amounts paid in settlement of any Proceeding effected without its prior written consent (which consent shall not be unreasonably withheld or delayed). The Company shall not, without the prior written consent of Indemnitee (which consent shall not be unreasonably withheld or delayed), enter into any settlement which (i) includes an admission of fault of Indemnitee, any non-monetary remedy imposed on Indemnitee or any monetary damages for which Indemnitee is not wholly and actually indemnified hereunder or (ii) with respect to any Proceeding with respect to which Indemnitee may be or is made a party or may be otherwise entitled to seek indemnification hereunder, does not include the full release of Indemnitee from all liability in respect of such Proceeding.

  • Incorporation of Administrative Code Provisions by Reference The provisions of Chapters 12B and 12C of the San Francisco Administrative Code are incorporated in this Section by reference and made a part of this Agreement as though fully set forth herein. Contractor shall comply fully with and be bound by all of the provisions that apply to this Agreement under such Chapters, including but not limited to the remedies provided in such Chapters. Without limiting the foregoing, Contractor understands that pursuant to §§12B.2(h) and 12C.3(g) of the San Francisco Administrative Code, a penalty of $50 for each person for each calendar day during which such person was discriminated against in violation of the provisions of this Agreement may be assessed against Contractor and/or deducted from any payments due Contractor.

  • Modification to Article III, Section 2 of the DPA Article III, Section 2 of the DPA (Annual Notification of Rights.) is amended as follows:

  • Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.

  • LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.

  • Jurisdiction and Process; Waiver of Jury Trial (a) The Company irrevocably submits to the non-exclusive jurisdiction of any New York State or federal court sitting in the Borough of Manhattan, The City of New York, over any suit, action or proceeding arising out of or relating to this Agreement or the Notes. To the fullest extent permitted by applicable law, the Company irrevocably waives and agrees not to assert, by way of motion, as a defense or otherwise, any claim that it is not subject to the jurisdiction of any such court, any objection that it may now or hereafter have to the laying of the venue of any such suit, action or proceeding brought in any such court and any claim that any such suit, action or proceeding brought in any such court has been brought in an inconvenient forum. (b) The Company agrees, to the fullest extent permitted by applicable law, that a final judgment in any suit, action or proceeding of the nature referred to in Section 23.8(a) brought in any such court shall be conclusive and binding upon it subject to rights of appeal, as the case may be, and may be enforced in the courts of the United States of America or the State of New York (or any other courts to the jurisdiction of which it or any of its assets is or may be subject) by a suit upon such judgment. (c) The Company consents to process being served by or on behalf of any holder of a Note in any suit, action or proceeding of the nature referred to in Section 23.8(a) by mailing a copy thereof by registered or certified or priority mail, postage prepaid, return receipt requested, or delivering a copy thereof in the manner for delivery of notices specified in Section 19, to the Process Agent, as its agent for the purpose of accepting service of any process in the United States. The Company agrees that such service upon receipt (i) shall be deemed in every respect effective service of process upon it in any such suit, action or proceeding and (ii) shall, to the fullest extent permitted by applicable law, be taken and held to be valid personal service upon and personal delivery to it. Notices hereunder shall be conclusively presumed received as evidenced by a delivery receipt furnished by the United States Postal Service or any reputable commercial delivery service. (d) Nothing in this Section 23.8 shall affect the right of any holder of a Note to serve process in any manner permitted by law, or limit any right that the holders of any of the Notes may have to bring proceedings against the Company in the courts of any appropriate jurisdiction or to enforce in any lawful manner a judgment obtained in one jurisdiction in any other jurisdiction. (e) The Company hereby irrevocably appoints the Process Agent to receive for it, and on its behalf, service of process in the United States. (f) THE PARTIES HERETO HEREBY WAIVE TRIAL BY JURY IN ANY ACTION BROUGHT ON OR WITH RESPECT TO THIS AGREEMENT, THE NOTES OR ANY OTHER DOCUMENT EXECUTED IN CONNECTION HEREWITH OR THEREWITH.

  • Authorization and Description of Securities The Securities to be purchased by the Underwriters from the Company have been duly authorized for issuance and sale to the Underwriters pursuant to this Agreement and, when issued and delivered by the Company pursuant to this Agreement against payment of the consideration set forth herein, will be validly issued and fully paid and non-assessable; and the issuance of the Securities is not subject to the preemptive or other similar rights of any securityholder of the Company. The Common Stock conforms to all statements relating thereto contained in the Registration Statement, the General Disclosure Package and the Prospectus and such description conforms to the rights set forth in the instruments defining the same. No holder of Securities will be subject to personal liability by reason of being such a holder.

  • Modification to Article VII, Section 4 of the DPA Article VI, Section 4 of the DPA (Annual Notification of Rights.) is amended as follows:

  • Invoicing for Charges Against the Judicial Council’s Master Account A. The Contractor shall establish a Master Account for the Judicial Council’s charges provided for under the exhibits of this Agreement. B. Charges to the Master Account shall be settled with Citibank CMC, as defined herein. C. The Contractor's final invoice for the Master Account shall include the Judicial Council Contract Number set forth on the face of this Agreement and shall be itemized to show the applicable and allowable charges by date and event/category/activity and number served, as appropriate. D. For performing the Work of this Agreement, the Contractor shall xxxx the Judicial Council for the total actual charges against the Master Account, based upon the prices stated herein and itemized to provide the following details, if applicable: i. Sleeping room charges as set forth in Exhibit C; ii. Meeting room rental charges as set forth in Exhibit D; iii. Food and beverage charges as set forth in Exhibit E; and/or iv. Charges for miscellaneous requirements as set forth in Exhibit F. E. If the Contract is terminated in whole or in part, pursuant to either the termination for cause provision or the Judicial Council’s obligation subject to availability of funds provision, as set forth in Exhibit A, the Contactor shall xxxx the Judicial Council for only those applicable and allowable charges accrued up to the effective date of termination, itemized as set forth above in this provision. F. If the Contract is terminated pursuant to the Termination Fee charge provision, as set forth in Exhibit B, the Contractor shall xxxx the Judicial Council for the allowable and applicable Termination Fee, as set forth in Table 2, below, and shall offset the Termination Fee by rental charges for the meeting and function rooms that the Contractor received from Third Parties during the Program

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!