Active Ingredient and Raw Materials Sample Clauses

Active Ingredient and Raw Materials. (a) SUPPLIER will at all times acquire, at its own cost and expense, the Active Ingredient and Raw Materials, in such quantities as are necessary to enable SUPPLIER to manufacture and supply the desired quantities of the Product during the term of this Agreement. SUPPLIER will perform all quality control procedures with respect to the Active Ingredient and Raw Materials in accordance with the Specifications. (b) SUPPLIER will, or will cause its Affiliates to, use its commercially reasonable efforts to provide PURCHASER with the Active Ingredient in the quantity, on the delivery date and at the price set forth on Schedule C hereto. In the event SUPPLIER or its Affiliate is unable to supply the Active Ingredient to PURCHASER on the delivery date set forth on Schedule C, SUPPLIER shall, or shall cause its Affiliate to, use its commercially reasonable efforts to deliver such Active Ingredient as soon as practicable thereafter, but in any event, no later than thirty (30) days after the original delivery date. (c) PURCHASER shall purchase from SUPPLIER the Active Ingredient in the quantities and on the delivery dates set forth in Schedule C. Subject to Section 10.3 hereof, in the event PURCHASER fails at any time to purchase all of the Active Ingredient manufactured and made available for delivery by SUPPLIER as specified in this Section 2.3(c), PURCHASER shall pay to SUPPLIER an amount equal to the total Production Fee which would otherwise have been paid to SUPPLIER had PURCHASER purchased the quantity specified on Schedule C on the applicable date.
Sample 1Sample 2
AutoNDA by SimpleDocs
Active Ingredient and Raw Materials. (a) SUPPLIER will at all times acquire, at its own cost and expense, the Active Ingredient and Raw Materials, in such quantities as are necessary to enable SUPPLIER to manufacture and supply the desired quantities of the Product during the term of this Agreement. SUPPLIER will perform all quality control procedures with respect to the Active Ingredient and Raw Materials in accordance with the Specifications. (b) SUPPLIER will use its commercially reasonable efforts to provide PURCHASER with the Active Ingredient in the quantity, on the delivery date and at the price set forth on Schedule B hereto. In the event SUPPLIER is unable to supply the Active Ingredient to PURCHASER on the delivery date set forth on Schedule B, SUPPLIER shall use its commercially reasonable efforts to deliver such Active Ingredient as soon as practicable thereafter, but in any event, no later than thirty (30) days after the original delivery date.
Sample 1

Related to Active Ingredient and Raw Materials

  • Raw Materials A. Catalent shall procure Raw Materials only from vendors that are approved in writing by Palatin or otherwise qualified in accordance with the provisions of the Quality Agreement. Catalent shall be responsible for procuring Raw Materials as necessary to meet the Firm Commitment. Catalent shall not be liable for any delay in delivery of Product if (i) Catalent is unable to obtain, in a timely manner, a particular Raw Material necessary for Processing and (ii) Catalent placed orders for such Raw Materials promptly following receipt of Palatin’s Firm Commitment. In the event that any Raw Material becomes subject to purchase lead time beyond the Firm Commitment time frame, the parties will negotiate in good faith an appropriate amendment to this Agreement, including Clause 4.2. B. In certain instances, Palatin may require a specific supplier, manufacturer or vendor (“Vendor”) to be used for Raw Material. In such an event, (i) such Vendor will be identified in the Specifications and (ii) the Raw Materials from such Vendor shall be deemed Palatin-supplied Materials for purposes of this Agreement. If the cost of the Raw Material from any such Vendor (other than a Vendor specified in the Specifications as of the Effective Date) is greater than Catalent’s costs for the same raw material of equal quality from other vendors, Catalent shall add the difference between Catalent’s cost of the Raw Material and the Vendor’s cost of the Raw Material to the Unit Pricing. Palatin will be responsible for all reasonable, out-of-pocket costs incurred by Catalent associated with qualification of any such Vendor who has not been previously qualified by Catalent. C. In the event of (i) a Specification change for any reason, (ii) obsolescence of any Raw Material or (iii) termination or expiry of this Agreement, Palatin shall bear the cost of any unused Raw Materials (including packaging), so long as Catalent (a) purchased such Raw Materials in quantities consistent with Palatin’s then current Firm Commitment and any minimum purchase obligations required by the vendor and (b) used commercially reasonable efforts to mitigate such costs by using any such unused Raw Materials in the manufacture of other products.

  • API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.

  • Equipment and Materials CONTRACTOR shall provide all equipment, materials, and supplies necessary for the performance on the Agreement except:

  • Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.

  • Products Products available under this Contract are limited to Software, including Software as a Service, products and related products as specified in Appendix C, Pricing Index. Vendor may incorporate changes to their product offering; however, any changes must be within the scope of products awarded based on the posting described in Section 1.B above. Vendor may not add a manufacturer’s product line which was not included in the Vendor’s response to the solicitation described in Section 1.B above.

  • Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing. (b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time. (c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request. (d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation. (e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.

  • Consumables During the design phase, Purchaser may participate in the selection of suppliers of consumables of the Supplier. In such case, the choice regarding the final selection of the said suppliers shall be mutually agreed between the Parties. Two suppliers shall be identified and selected for each type of consumables.

  • Defective Products A defective product may be returned to PRECISIONARY INSTRUMENTS within thirty (30) days of the delivery date for a refund of the original purchase price with the following amendments/fees. To return a defective product, please contact our Customer Service Department and follow the Return of Products Instructions below.

  • Personnel Equipment and Material Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services, and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the reasonable opinion of County, is incompetent or whose conduct becomes detrimental to the Engineering Services shall immediately be removed from association with the Project when so instructed by County. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than County. Engineer may not change the Project Manager without prior written consent of County.

  • Quality of Materials and workmanship The Contractor shall ensure that the Construction, Materials and workmanship are in accordance with the requirements specified in this Agreement, Specifications and Standards and Good Industry Practice.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!