Agency Oversight Sample Clauses

Agency Oversight a. The Agency shall evaluate the Health Plan’s QIP and PMs at least one (1) time per year at dates to be determined by the Agency, or as otherwise specified by this Contract. b. The Health Plan, in conjunction with the Agency, shall participate in workgroups to design additional QI strategies and to learn to use the best practice methods for enhancing the Quality of health care provided to Enrollees. c. If the PIPs, CAHPS, the PMs, the annual Medical Record audit or the EQRO indicate that the Health Plan's performance is not acceptable, then the Agency may restrict the Health Plan’s Enrollment activities including, but not limited to, termination of Mandatory Assignments. d. If the Agency determines that the Health Plan’s performance is not acceptable, the Agency shall require the Health Plan to submit a corrective action plan (CAP). f the Health Plan fails to provide a CAP within the time specified by the Agency, the Agency shall sanction the Health Plan, in accordance with the provisions of Section XIV, Sanctions, and may immediately terminate all Enrollment activities and Mandatory Assignments. When considering whether to impose a limitation on Enrollment activities or Mandatory Assignment, the Agency may take into account the Health Plan’s cumulative performance on all QI activities. e. Annual Medical Record Audit (1) The Health Plan shall furnish specific data requested by the Agency in order to conduct the Medical Record audit. (2) If the Medical Record audit indicates that Quality of care is not acceptable, pursuant to contractual requirements, the Agency shall sanction the Health Plan, in accordance with the provisions of Section XIV, Sanctions, and may immediately terminate all Enrollment activities and Mandatory Assignments, until the Health Plan attains an acceptable level of Quality of care as determined by the Agency.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
Agency Oversight. In addition to the Service, Credit and Debit projects may fall under the jurisdiction of the following agencies: 1. Wyoming Game and Fish Department (WGFD) [Description to be developed with input from WGFD]
Sample 1

Related to Agency Oversight

  • Emergency Operations 6:01 In the event of an emergency which could endanger the health or safety of the public, employees shall unite to meet the emergency and shall, until the danger has been brought under control, perform such duties as may be required of them regardless of their occupation.

  • Agency of Human Services The Agency of Human Services is responsible for overseeing all contracts and grants entered by any of its departments, boards, offices and business units, however denominated. The Agency of Human Services, through the business office of the Office of the Secretary, and through its Field Services Directors, will share with any named AHS-associated party to this Agreement oversight, monitoring and enforcement responsibilities. Party agrees to cooperate with both the named AHS-associated party to this contract and with the Agency of Human Services itself with respect to the resolution of any issues relating to the performance and interpretation of this Agreement, payment matters and legal compliance.

  • Construction Administration Redeveloper shall be responsible for all components of the Redeveloper Improvements constructed by Redeveloper including construction management, coordination of contractors and regulatory permitting and other requirements. Redeveloper and its contractor(s) shall reasonably cooperate with City contractors performing work in the vicinity of the Redevelopment Project Area including, but not limited to, Redeveloper's scheduling of its work to provide for a smooth sequence of operations. The Redeveloper will be solely responsible for payment of all construction costs for the Redeveloper Improvements as set forth in this Redevelopment Agreement.

  • Agreement Administration SBBC has delegated authority to the Superintendent of Schools or his/her designee to take any actions necessary to implement and administer this Agreement.

  • Project Administration The Contractor shall provide project administration for all Subcontractors, vendors, suppliers, and others involved in implementing the Work and shall coordinate administration efforts with those of the A/E and ODR in accordance with these Uniform General and Supplementary Conditions and provisions of Division 1 Specifications, and as outlined in the Pre- construction Conference.

  • Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.

  • Settlement Administration 5.1. The Settlement Administrator shall, under the supervision of the Court, administer the relief provided by this Settlement Agreement by processing Claim Forms in a rational, responsive, cost effective, and timely manner. The Settlement Administrator shall maintain reasonably detailed records of its activities under this Settlement Agreement. The Settlement Administrator shall maintain all such records as are required by applicable law in accordance with its normal business practices and such records will be made available to Class Counsel and Defendant’s Counsel upon request. The Settlement Administrator shall also provide reports and other information to the Court as the Court may require. The Settlement Administrator shall provide Class Counsel and Defendant’s Counsel with information concerning Notice, administration, and implementation of the Settlement Agreement. Should the Court request, the Parties, in conjunction with the Settlement Administrator, shall submit a timely report to the Court summarizing the work performed by the Settlement Administrator, including a report of all amounts from the State-Specific Settlement Funds paid on account of Approved Claims. Without limiting the foregoing, the Settlement Administrator shall: (a) receive exclusion forms and other requests from Settlement Class Members and promptly provide a copy of such requests to Class Counsel and Defendant’s Counsel upon receipt. If the Settlement Administrator receives any exclusion forms or other requests from the Settlement Class after the Objection/Exclusion Deadline, the Settlement Administrator shall promptly provide copies thereof to Class Counsel and Defendant’s Counsel; (b) provide weekly reports to Class Counsel and Defendant’s Counsel, including, without limitation, reports regarding the number of Claim Forms received, the current number approved by the Settlement Administrator at that time from each of the Settlement Classes, and the number of opt-outs received; (c) make available for inspection by Class Counsel or Defendant’s Counsel the Claim Forms, any documentation submitted in support thereof, and any correspondence received by the Settlement Administrator at any time upon reasonable notice; (d) pay all Approved Claims according to the terms of this Settlement Agreement; (e) make all tax filings related to the Escrow Accounts, including making any required “information returns” as that term is used in 26 U.S.C. § 1, et seq. Neither Class Counsel nor Defendant makes any representations regarding the tax treatment of the Escrow Account, State-Specific Settlement Funds or any portion thereof; and (f) respond to questions about the Settlement from Settlement Class Members. 5.2. The Settlement Administrator shall employ reasonable procedures to screen claims for abuse or fraud. The Settlement Administrator, after consultation with Class Counsel, shall reject Claim Forms where there is evidence of abuse or fraud. 5.3. The Settlement Administrator shall reject any Claim Form that does not contain all requested information. The Settlement Administrator shall provide the individual with an opportunity to cure any deficient Claim Form within twenty-one (21) days after notice to such individual. If the individual fails to cure within the required time, the claim shall be rejected. 5.4. In the exercise of their duties outlined in this Agreement, the Settlement Administrator shall have the right to reasonably request additional information from the Parties or any Settlement Class Member.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Agency Responsibilities Agency is responsible for (a) Agency’s use of Axon Devices; (b) breach of this Agreement or violation of applicable law by Agency or an Agency end user; and (c) a dispute between Agency and a third-party over Agency’s use of Axon Devices.

  • Emergency Operator Access Registry Operator shall provide bulk access to the zone files for the TLD to the Emergency Operators designated by ICANN on a continuous basis in the manner ICANN may reasonably specify from time to time.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!