Office and Support Staff During the Employment Period, the Executive shall be entitled to an office or offices of a size and with furnishings and other appointments, and to exclusive personal secretarial and other assistance, at least equal to the most favorable of the foregoing provided to the Executive by the Company and its affiliated companies at any time during the 120-day period immediately preceding the Effective Date or, if more favorable to the Executive, as provided generally at any time thereafter with respect to other peer executives of the Company and its affiliated companies.
Statewide HUB Program Statewide Procurement Division Note: In order for State agencies and institutions of higher education (universities) to be credited for utilizing this business as a HUB, they must award payment under the Certificate/VID Number identified above. Agencies, universities and prime contractors are encouraged to verify the company’s HUB certification prior to issuing a notice of award by accessing the Internet (xxxxx://xxxxx.xxx.xxxxx.xx.xx/tpasscmblsearch/index.jsp) or by contacting
Training and Support Licensor shall offer installation support to the Licensee and each of the Members, including assisting with the implementation of any Licensor software. Licensor will provide appropriate training to Licensee and Member staff relating to the use of the Licensed Materials and any Licensor software. Licensor will offer reasonable levels of continuing support to assist Licensee and Members in use of the Licensed Materials, including providing help files and other appropriate user documentation in connection with the use of and access to Licensed Materials. Licensor will, at a minimum, make its personnel available by email, telephone or via the Web, or in person during Licensor’s regular business hours, Monday through Friday, for training and user access support.
Services and Support 1.1 In exchange for your continued compliance with this Agreement, and any modification to this Agreement made by Intuit in accordance with Sections A.1.1, you shall have access to the Software/Subscription in accordance with the following provisions:
(a) If you purchased a Subscription based license for the Software, which generally means that you will be paying for your use of the Software and Services on a monthly or annual basis, you shall receive as part of your active Subscription, so long as Intuit is receiving the applicable payment from you: (i) access to the features of the Software subscribed to by you; (ii) Updates and Enhancements; (iii) Version Protection, each defined in Section B.1.2 below; and (iv) additional products, services and/or discounts when and if they should be made available to you. If you have purchased a subscription that includes Support you will also be entitled to receive Support Services as defined below. Software licenses obtained through a subscription are eligible for Enhancements during the active subscription period only. The Subscription is cancellable by you in accordance with this Agreement, but you will not be entitled to any refunds if you cancel after the 60-Day Money Back Guarantee period, as defined in Section B.6. If you cancel your Subscription or if we do not receive the payment for your Subscription, or if the Subscription is in any way terminated in accordance with the terms of this Agreement, you will no longer have access to the Software and all related Services defined above upon the expiration of the current Subscription term, but you will retain access to your company data file stored on your device, which can be reinstated to a readable QuickBooks format upon reactivation of your Subscription or with the purchase of a license on the Software.
(b) If you purchased your license to the Software under a one-time, upfront payment at retail or directly from Intuit and not under a Subscription, you shall receive: (i) a license to the specific version of the Software product you have selected that, subject to the license grant and restrictions in Section A.1.1, allows you access to the features of the Software; and (ii) Updates and Enhancements to the Software in accordance with the terms of the Termination provisions. Intuit's obligations under this Section B.1.1 are contingent upon you installing all updates and error corrections within thirty (30) days of being notified of their availability by Intuit (or its Representatives). QuickBooks 2015 Software purchased on a separate standalone basis are eligible for enhancements on a when-and-if available basis through May 31, 2018, which is the current support period for QuickBooks 2015.
Qualified Medical Child Support Order A child who would otherwise meet the eligibility requirements and is required to be covered by a Qualified Medical Child Support Order (QMCSO) is considered an eligible dependent.
Initial Decision Maker The Architect will serve as the Initial Decision Maker pursuant to Article 15 of AIA Document A201–2017, unless the parties appoint below another individual, not a party to this Agreement, to serve as the Initial Decision Maker.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Service and Support 1. Brainlab shall be responsible for providing service and support for the Brainlab Technology in all Fields of Use. Brainlab shall be responsible for providing Xxxxx 0 and Level 2 service and support to customers for Products sold by Brainlab in the Therapeutic Delivery Field of Use and for Integrated Products sold by Brainlab in the MR Guided Stereotactic Placement Field of Use. Level 1 support shall include onsite training, help desk services, reseller interfacing, problem isolation and diagnosis, and Level 2 support shall include loading bug fixes, patches, and minor repair services. To the extent relating to SurgiVision Technology, SurgiVision shall provide Level 3 support, which shall include backup support services to assist Brainlab in meeting Level 1 and Level 2 support obligations by addressing certain technical support issues that are beyond the scope of Brainlab’s expertise. Brainlab will pay SurgiVision for Xxxxx 0 support services at standard rates as described in Appendix C, provided that such services were not required for Co-Development and Distribution Agreement between SurgiVision, Inc. and Brainlab Aktiengesellschaft CONFIDENTIAL warranty repair as contemplated in section X.3 below. Appendix C may be changed from time to time, as appropriate upon the mutual agreement of Brainlab and SurgiVision. SurgiVision will provide spare parts and other items for service to Brainlab at a price equal to [***]. Brainlab reserves the right to offer service packages to the end customer at its discretion.
2. SurgiVision shall be responsible for providing service and support to customers in the United States for ClearPoint Products sold in the MR Guided Stereotactic Placement Field of Use; provided, however, that SurgiVision shall be responsible for attending only the initial clinical cases using the ClearPoint Products (to the extent attendance is requested by the customer). For the avoidance of any doubt, the foregoing obligation does not apply to Integrated Products. To the extent Brainlab has a service package with the end user customer that covers ClearPoint Products (not including Integrated Products), SurgiVision shall be entitled to reasonable compensation from Brainlab under such arrangement in an amount to be agreed.
3. SurgiVision shall provide training on the ClearPoint Products, including joint attendance of SurgiVision and Brainlab personnel in initial clinical cases in the applicable region, to Brainlab personnel to enable Brainlab personnel to provide service and support to customers outside of the United States.
