Architect Representation Sample Clauses

Architect Representation. 2.3.1 The Architect shall provide a list of all consultants which the Architect intends to utilize relating to the Project. The list shall include such information on the qualifications of the consultants as may be requested by the Owner. The Owner reserves the right to review the consultants proposed, and the Architect shall not retain a consultant to which the Owner has a reasonable objection. The Owner shall pay the Architect any increased costs of obtaining the services of consultants to replace those rejected by the Owner. 2.3.2 The Architect shall provide to the Owner a list of the proposed key project personnel of the Architect and its consultants to be assigned to the Project. This list shall include information on the professional background of each of the assigned personnel, as may be requested by the Owner, through the Construction Program Manager. Such key personnel and consultants shall be satisfactory to the Owner and shall not be changed except with the consent of the Owner. The Owner's approval of substituted personnel shall not be unreasonably withheld.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Architect Representation. The Architect shall designate a Project Architect and/or Architectural Project Manager for all Phases of Basic Services. The Architect's Project Architect and/or Architectural Project Manager shall be reasonably satisfactory to the District and shall not be removed or replaced without prior written approval of the District. In seeking to replace an approved Project Architect and/or Architectural Project Manager, the Architect shall provide the District with a request in writing specifying the reason for the substitution or replacement and including the resume and qualifications of the proposed Project Architect and/or Architectural Project Manager. Notwithstanding any approval by the District of a Project Architect and/or Architectural Project Manager, the District reserves the right to require the removal and/or replacement of any Project Architect and/or Architectural Project Manager in its sole discretion and at no expense to the District. The Project Architect and/or Architectural Project Manager shall have the overall responsibility for performance of Architect’s obligations hereunder and be authorized to act on behalf of the Architect in discharge of Architect’s services hereunder. During the Construction Phase, the Project Architect and/or Architectural Project Manager shall be readily available and provide by telephone, telecopier, correspondence or other
Sample 1
Architect Representation. The Architect shall designate a Project Architect and/or Job Captain for all Phases of Basic Services for an Assigned Project. Unless approved by the District for an Assigned Project, the Project Architect or Job Captain designated by the Architect for an Assigned Project shall be the same for all Phases of Basic Services for the Assigned Project. The Architect’s Project Architect and/or Job Captain shall: (i) be reasonably satisfactory to the District; (ii) will not be replaced without approval of the District; (iii) shall have the overall responsibility for performance of Architect’s obligations hereunder; and (iv) be authorized to act on behalf of the Architect in discharge of Architect’s services hereunder. If the Project Architect or Job Captain designated by the Architect for an Assigned Project is replaced, the District shall have the right to approve of the replacement Project Architect or Job Captain for the Assigned Project. During the Construction Phase of an Assigned Project, the Project Architect and/or Job Captain shall be readily available to communicate by telephone, correspondence, necessary Site visits, e-mail or other means of communication to provide design direction and decisions as necessary to avoid delay, hindrance or interruption to construction of the Assigned Project.
Sample 1
Architect Representation. The Architect shall designate a Project Architect for all Phases of Basic Services for an Assigned Project. The Architect’s Project Architect shall: (a) be reasonably satisfactory to the District; (b) will not be replaced without approval of the District;
Sample 1
Architect Representation. The Architect shall designate a Project Architect and/or Architectural Project Manager for all Phases of Basic Services for an Assigned Project. The Architect's Project Architect and/or Architectural Project Manager shall be reasonably satisfactory to the District and shall not be removed or replaced without prior written approval of the District. In seeking to replace an approved Project Architect and/or Architectural Project Manager for an Assigned Project, the Architect shall provide the District with a request in writing specifying the reason for the substitution or replacement and including the resume and qualifications of the proposed Project Architect and/or Architectural Project Manager. Notwithstanding any approval by the District of a Project Architect and/or Architectural Project Manager, the District reserves the right to require the removal and/or replacement of any Project Architect and/or Architectural Project Manager in its sole discretion and at no expense to the District. The Project Architect and/or Architectural Project Manager shall have the overall responsibility for performance of Architect’s obligations of the Project Assignment for an Assigned Project and be authorized to act on behalf of the Architect in discharge of Architect’s services thereunder. During the Construction Phase, the Project Architect and/or Architectural Project Manager shall be readily available and provide by telephone, telecopier, correspondence or other means of communication to
Sample 1
Architect Representation. The Architect shall designate a Job Captain or Project Architect for all Phases of the Basic Services (“the Architect Representative”). The Architect Representative shall be reasonably satisfactory to the District and shall not be replaced without the prior approval and consent of the District. The Architect Representative shall have the overall responsibility for directing and ensuring the Architect’s complete and timely performance of its obligations hereunder. During the Construction Phase of the Basic Services, the Architect Representative shall be readily available by telephone, telecopier, email, pager or other means of communications to provide design direction and decisions as necessary to avoid delay, hindrance or interruption to Project construction.
Sample 1
Architect Representation. The Architect shall designate a Project Manager for all Phases of Basic Services who shall: (i) be reasonably satisfactory to the District; (ii) will not be replaced without approval of the District; (iii) shall have the overall responsibility for performance of Architect’s obligations hereunder; and (iv) be authorized to act on behalf of the Architect in discharge of Architect’s obligations hereunder. If the Architect’s Project Manager is replaced, the District shall have the right to approve of the replacement Project Architect. At all times during Performance of Basic Services, the Project Manager shall be readily available to communicate by telephone, email, Site visits, or other means of communication to provide design direction and decisions as necessary to avoid delay, hindrance or interruption to completion of Project design, bidding or construction.
Sample 1
AutoNDA by SimpleDocs

Related to Architect Representation

  • Independent Representation Each party hereto acknowledges and agrees that it has received or has had the opportunity to receive independent legal counsel of its own choice and that it has been sufficiently apprised of its rights and responsibilities with regard to the substance of this Agreement.

  • Client Representations CLIENT represents to VCS that: a. The execution, delivery and performance of this Agreement by CLIENT and the consummation of the transactions contemplated hereby have been duly authorized by all requisite corporate action; this Agreement constitutes the legal, valid and binding obligation of CLIENT, enforceable in accordance with its terms (except to the extent enforcement is limited by bankruptcy, insolvency, reorganization or other Laws affecting creditors’ rights generally and by general principles of equity); and this Agreement and CLIENT’s performance hereunder does not violate or constitute a breach under any organizational document of CLIENT or any contract, other form of agreement, or judgment or order to which CLIENT is a party or by which it is bound. b. CLIENT shall adhere to and comply with all applicable Laws in carrying out its obligations under this Agreement. c. CLIENT will maintain insurance with financially sound carriers or through one or more financially sound self-insurance arrangements in the amounts and types (and with the deductibles or retentions) as set forth in Schedule C to this Agreement, as the same may be amended from time to time. d. During the Term of this Agreement and for a period of *** (***) months thereafter (except if this Agreement is terminated by CLIENT under Section 11.1(a) or Section 11.1(b), in which case this provision shall not survive termination), CLIENT shall not (i) solicit or hire any VCS Field Force member or pay or offer to pay any VCS Field Force member any compensation or benefits (it being understood that the payments by CLIENT to VCS contemplated by this Agreement will not violate this provision), except, in each case, in connection with a Conversion; (ii) provide any contact information (including name, address, phone number or e-mail address) concerning members of the VCS Field Force to any third party providing (or proposing to provide) contract sales services and promotional services to CLIENT; or (iii) assist actively in any other way such a third party in employing or retaining members of the VCS Field Force. For the purposes of this Agreement, the term “solicit” shall not include general advertising by CLIENT for personnel not specifically directed to a VCS Field Force member. e. CLIENT has the lawful authority necessary to market and sell the Products in all geographic regions where the Products are to be promoted under this Agreement. f. CLIENT is solely responsible for reviewing and approving any of its product promotional materials and literature and any other materials or information provided by it to VCS and for ensuring all such materials or information comply with Laws.

  • Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.

  • COMPANY REPRESENTATIONS, ETC The Company represents and warrants to the Buyer that:

  • Tenant Representations Each person executing this Amendment on behalf of Tenant represents and warrants to Landlord that: (a) Tenant is properly formed and validly existing under the laws of the state in which Tenant is formed and Tenant is authorized to transact business in the state in which the Building is located; (b) Tenant has full right and authority to enter into this Amendment and to perform all of Tenant’s obligations hereunder; and (c) each person (and both persons if more than one signs) signing this Amendment on behalf of Tenant is duly and validly authorized to do so.

  • Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • CONTRACTOR’S REPRESENTATIONS In order to induce the City to enter into this Work Order, the Contractor makes the following representations: 7.1 Contractor has familiarized itself with the nature and extent of the Contract Documents including this Work Order, work, site, locality, and all local conditions and laws and regulations that in any manner may affect cost, progress, performance or furnishing of the work. 7.2 Contractor has obtained at his/her own expense and carefully studied, or assumes responsibility for obtaining and carefully studying, soil investigations, explorations, and test reports which pertain to the subsurface conditions at or contiguous to the site or otherwise may affect the cost, progress, performance or furnishing of the work as Contractor considers necessary for the performance or furnishing of the work at the stated work order price within the Work Order stated time and in accordance with the other terms and conditions of the Contract Documents, including specifically the provisions of the IFB; and no additional examinations, investigations, explorations, tests, reports, studies or similar information or data are or is deemed necessary by Contractor for such purposes. 7.3 Contractor has reviewed and checked all information and data shown or indicated on the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of said Underground Facilities. No additional examinations, investigations, explorations, tests, reports, studies or similar information or data in respect of said Underground Facilities are or is deemed necessary by the Contractor in order to perform and furnish the work under this Work Order price, within the Work Order time and in accordance with the other terms and conditions of the Contract Documents. 7.4 Contractor has correlated the results of all such observations, examinations, investigations, explorations, tests, reports and studies with the terms and conditions of the Contract Documents. 7.5 Contractor has given the City’s Contract Administrator written notice of all conflicts, errors or discrepancies that he or she has discovered in the Contract Documents and the written resolution thereof by City or its designee is acceptable to the Contractor.

  • Joint Representations Each party represents and warrants, which representations and warranties shall be deemed to be continuing throughout the term of this Agreement, that: (A) It is a corporation, partnership, trust, or other entity duly organized and validly existing in good standing under the laws of the jurisdiction in which it is organized. (B) To the extent required by Applicable Law (defined below), it is duly registered with all appropriate regulatory agencies or self-regulatory organizations and such registration will remain in full force and effect for the duration of this Agreement. (C) For the duties and responsibilities under this Agreement, it is currently and will continue to abide by all applicable federal and state laws, including, without limitation, federal and state securities laws; regulations, rules, and interpretations of the SEC and its authorized regulatory agencies and organizations, including FINRA; and all other self-regulatory organizations governing the transactions contemplated under this Agreement (collectively, “Applicable Law”). (D) It has duly authorized the execution and delivery of this Agreement and the performance of the transactions, duties, and responsibilities contemplated by this Agreement. (E) This Agreement constitutes a legal obligation of the party, subject to bankruptcy, insolvency, reorganization, moratorium, and other laws of general application affecting the rights and remedies of creditors and secured parties. (F) Whenever, in the course of performing its duties under this Agreement, it determines that a violation of Applicable Law has occurred, or that, to its knowledge, a possible violation of Applicable Law may have occurred, or with the passage of time could occur, it shall promptly notify the other party of such violation.

  • Contractor Representations Contractor represents and warrants to Subcontractor as follows: (a) Contractor (i) is duly organized, validly existing and in good standing under the laws of its state of incorporation or organization, (ii) has the power and authority to own its properties and to carry on business as now being conducted, and (iii) has the power to execute and deliver this Subcontract; (b) The execution and performance by Contractor of the terms and provisions of this Subcontract by Contractor have been duly authorized by all requisite action, and neither the execution nor the performance of this Subcontract will violate any provision of law, any order of any court or other agency of government, the organizational documents of Contractor or any indenture, agreement or other instrument to which Contractor is a party, or by which Contractor is bound, or be in conflict with, result in a breach of, or constitute (with due notice or lapse of time or both) a default under, or except as may be provided by this Subcontract, result in the creation or imposition of any lien, charge or encumbrance of any nature whatsoever upon any of the property or assets of Contractor pursuant to, any such indenture agreement or instrument; (c) Contractor has obtained all licenses, permits and approvals required to perform the Services to be provided by Contractor under the Prime Contract; and (d) Contractor is not under suspension or debarment by the Commonwealth or any other governmental entity, instrumentality or authority.

  • Investment Representation The Holder hereby represents and covenants that (a) any share of Stock acquired upon the vesting of the Award will be acquired for investment and not with a view to the distribution thereof within the meaning of the Securities Act of 1933, as amended (the “Securities Act”), unless such acquisition has been registered under the Securities Act and any applicable state securities laws; (b) any subsequent sale of any such shares shall be made either pursuant to an effective registration statement under the Securities Act and any applicable state securities laws, or pursuant to an exemption from registration under the Securities Act and such state securities laws; and (c) if requested by the Company, the Holder shall submit a written statement, in form satisfactory to the Company, to the effect that such representation (x) is true and correct as of the date of vesting of any shares of Stock hereunder or (y) is true and correct as of the date of any sale of any such share, as applicable. As a further condition precedent to the delivery to the Holder of any shares of Stock subject to the Award, the Holder shall comply with all regulations and requirements of any regulatory authority having control of or supervision over the issuance or delivery of the shares and, in connection therewith, shall execute any documents which the Board shall in its sole discretion deem necessary or advisable.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!