Additional Indemnification by the Servicer; Third Party Claims The Servicer shall indemnify the Seller, the Depositor, the Trustee and the Master Servicer (and each of their respective directors, officers, employees and agents) and the Trust Fund, and hold them harmless against any and all Costs that any such indemnified party may sustain in any way related to (i) the failure of the Servicer to perform its duties and service the Mortgage Loans in material compliance with the terms of this Agreement (including, but not limited to its obligation to provide the certification pursuant to Section 5.03(b) hereunder) or for any inaccurate or misleading information provided in the certification required pursuant to Section 5.03(b) or (ii) the failure of the Servicer to cause any event to occur or not to occur which would have occurred or would not have occurred, as applicable, if the Servicer were applying Accepted Servicing Practices under this Agreement. The Servicer shall immediately notify the Seller, the Depositor, the Master Servicer, the Trustee or any other relevant party if a claim is made by a third party with respect to this Agreement or the Mortgage Loans, assume (with the prior written consent of the indemnified party in the event of an indemnified claim) the defense of any such claim and pay all expenses in connection therewith, including counsel fees, promptly pay, discharge and satisfy any judgment or decree which may be entered against it or any other party in respect of such claim and follow any written instructions received from such indemnifying party in connection with such claim. Subject to the Servicer’s indemnification pursuant to Section 6.02, or the failure of the Servicer to service and administer the Mortgage Loans in material compliance with the terms of this Agreement, the Trust Fund shall indemnify the Servicer and hold the Servicer harmless against any and all Costs that the Servicer may sustain in connection with any legal action relating to this Agreement, the Certificates or the origination or Servicing of the Mortgage Loans by any prior owner or servicer, other than any Costs incurred by reason of the Servicer’s willful misfeasance, bad faith or negligence in the performance of duties hereunder or by reason of its reckless disregard of obligations and duties hereunder.
TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
Action by the Superintendent The Superintendent shall determine which of the alternative courses of action is proper and shall take appropriate action to implement such determination.
Additional Indemnification by the Seller; Third Party Claims (a) The Seller shall indemnify any Purchaser and its present and former directors, officers, employees and agents and the Successor Servicer and its present and former directors, officers, employees and agents, and hold such parties harmless against any and all claims, losses, damages, penalties, fines, forfeitures, legal fees and expenses (including legal fees and expenses incurred in connection with the enforcement of the Seller's indemnification obligation under this Subsection 14.01) and related costs, judgments, and any other costs, fees and expenses that such parties may sustain in any way related to the failure of the Seller to perform its duties and the Interim Servicer to service the Mortgage Loans in strict compliance with the terms of this Agreement or any Reconstitution Agreement entered into pursuant to Section 13 or any breach of any of Seller's representations, warranties and covenants set forth in this Agreement. For purposes of this clause "Purchaser" shall mean the Person then acting as the Purchaser under this Agreement and any and all Persons who previously were "Purchasers" under this Agreement and "Successor Servicer" shall mean any Person designated as the Successor Servicer pursuant to this Agreement and any and all Persons who previously were "Successor Servicers" pursuant to this Agreement.
Cooperation by the Company If any Shareholder shall transfer any Registrable Securities pursuant to Rule 144, the Company shall cooperate, to the extent commercially reasonable, with such Shareholder and shall provide to such Shareholder such information as such Shareholder shall reasonably request.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11:
(a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event;
(b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5;
(c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party.
(d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
Termination by the University i) The university may terminate this agreement under the following circumstances:
Action by the Board (a) Meetings of the Board may be called by any Manager upon two (2) days prior written notice to each Manager. The presence of a majority of the Managers then in office shall constitute a quorum at any meeting of the Board. All actions of the Board shall require the affirmative vote of a majority of the Managers then in office.
(b) Meetings of the Board may be conducted in person or by conference telephone facilities. Any action required or permitted to be taken at any meeting of the Board may be taken without a meeting if such number of Managers sufficient to approve such action pursuant to the terms of this Agreement consent thereto in writing. Notice of any meeting may be waived by any Manager.
Action by Agent The obligations of the Agent hereunder are only those expressly set forth herein. Without limiting the generality of the foregoing, the Agent shall not be required to take any action with respect to any Default, except as expressly provided in Article 6.
Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
