Authorization to Proceed Date; Long Lead Item Release Date Sample Clauses

Authorization to Proceed Date; Long Lead Item Release Date. On or before February 2, 2005 (herein called the “Authorization to Proceed Date”), Tenant shall give Landlord written authorization to proceed with the Additional Tenant Work in accordance with the Tenant’s Plan and Exhibit B-1 (such notice being referred to as the “Notice to Proceed”). In addition, Tenant shall promptly execute and deliver to Landlord any affidavits and documentation required in order to obtain all permits and approvals necessary for Landlord to commence and complete the Work on a timely basis (“Permit Documentation”). Further, Tenant shall, on or before January 14, 2005 (herein called the “Long Lead Item Release Date”), give Landlord written authorization to proceed to purchase and/or contract for the “Long Lead Items” (defined above). Notwithstanding the foregoing, Tenant acknowledges that (i) certain Long Lead Items may still delay completion of the Work and thus result in a Tenant Delay even if Tenant does authorize them on or before the Long Lead Item Release Date, and (ii) any Long Lead Items which are added as a result of a change order after the Long Lead Item Release Date may delay completion of the Work and thus result in a Tenant Delay.
Sample 1
AutoNDA by SimpleDocs
Authorization to Proceed Date; Long Lead Item Release Date. Tenant shall, on or before the Authorization to Proceed Date, give Landlord written authorization to proceed with Landlord’s Work in accordance with Tenant’s approved Plans (“Notice to Proceed”). Notwithstanding anything to the contrary herein contained, if, for any reason other than a breach by Landlord in its obligations under this Exhibit B, Tenant does not, on or before the Authorization Proceed Date, approve Landlord’s statement of Tenant Plan Excess Costs and authorize Landlord in writing to commence the performance of Landlord’s Work, then any delay in the performance of Landlord’s Work arising from such failure by Tenant shall be considered to be a Tenant Delay.
Sample 1

Related to Authorization to Proceed Date; Long Lead Item Release Date

  • Authorization to Proceed A fully executed and approved authorization in the form of Attachment 6 to this Agreement, Authorization to Proceed (“ATP”) accompanied by an executed purchase order document issued by the Owner to the Project Consultant, authorizing the performance of specific professional services, authorizing commencement of a Phase as defined in Article 2.1 through Article 2.8, and stating the time for completion and the amount of fee authorized for such services.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Modifications and Updates to the Wire Center List and Subsequent Transition Periods 5.4.6.1 In the event AT&T identifies additional wire centers that meet the criteria set forth in Sections 5.4.2.1 or 5.4.2.2 above, but that were not included in the Master List of Unimpaired Wire Centers or AT&T’s List of Unimpaired Wire Centers, AT&T shall include such additional wire centers in a CNL. Each such list of additional wire centers shall be considered a Subsequent Wire Center List. AT&T will follow any limitations on the frequency with which it may issue such lists and notification procedures set forth in applicable Commission orders. 5.4.6.2 TWTC shall have thirty (30) business days to dispute the additional wire centers listed on AT&T’s CNL. Absent such dispute, effective thirty (30) business days after the date of a AT&T CNL providing a Subsequent Wire Center List, AT&T shall not be required to provide DS1 and DS3 Dedicated Transport, as applicable, in such additional wire center(s), except pursuant to the self-certification process as set forth in Section 1.9.1 of this Attachment. 5.4.6.3 For purposes of Section 5.4.6.1 above, AT&T shall make available DS1 and DS3 Dedicated Transport that were in service for TWTC in a wire center on the Subsequent Wire Center List as of the thirtieth (30th) business day after the date of AT&T’s CNL identifying the Subsequent Wire Center List (Subsequent Embedded Base) until one hundred eighty (180) days after the thirtieth (30th) business day Version: 4Q06 Standard ICA 11/30/06 from the date of AT&T’s CNL identifying the Subsequent Wire Center List (Subsequent Transition Period). 5.4.6.4 The rates set forth in Exhibit B shall apply to the Subsequent Embedded Base during the Subsequent Transition Period. 5.4.6.5 No later than one hundred eighty (180) days from AT&T’s CNL identifying the Subsequent Wire Center List, TWTC shall submit an LSR(s) or spreadsheet(s) as applicable, identifying the Subsequent Embedded Base of circuits to be disconnected or converted to other AT&T services. 5.4.6.5.1 In the case of disconnection, the applicable disconnect charges set forth in this Agreement shall apply. 5.4.6.5.2 If TWTC chooses to convert DS1 and/or DS3 Dedicated Transport to special access circuits in existence as of the Effective Date of this Agreement, AT&T will include such DS1 and/or DS3 Dedicated Transport within TWTC’s total special access circuits, and apply any discounts to which TWTC is entitled from the transition period of 3/11/2006 to the conversion date. Conversions will be subject to the switch-as-is charge set forth in Exhibit A to this Attachment 2. 5.4.6.5.3 AT&T shall not impose disconnect or nonrecurring installation charges when transitioning the Subsequent Embedded Base of DS1 and DS3 Dedicated Transport in existence as of the Effective Date of this Agreement. 5.4.6.6 If TWTC fails to submit the LSR(s) or spreadsheet(s) for all of its Subsequent Embedded Base by one hundred eighty (180) days after the date of AT&T’s CNL identifying the Subsequent Wire Center List, AT&T will identify TWTC’s remaining Subsequent Embedded Base, if any, and will transition such circuits to the equivalent tariffed AT&T service(s), or in the case of Georgia, to the equivalent 271 service(s) set forth in Exhibit 1. In the states of Florida, Kentucky, Mississippi and South Carolina, those circuits identified and transitioned by AT&T shall be subject to the applicable disconnect charges as set forth in this Agreement and the full nonrecurring charges for installation of the equivalent tariffed AT&T service as set forth in AT&T’s tariffs. In the states of Alabama, Georgia, North Carolina and Tennessee, those circuits identified and transitioned by AT&T shall be subject to the applicable switch-as-is rates set forth in Exhibit A of Attachment

  • Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements

  • Notice to Proceed Work shall not commence on this Project until the Director has issued a written Notice to Proceed to the Recipient. Such Notice will not be issued until the Director is assured that the Recipient has complied with the Recipient's responsibilities concerning OEPA plan approval, when applicable. A Notice to Proceed shall be required for all project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Four-Digit Date Compliance If this Agreement includes the purchase of systems, software, or instrumentation with imbedded chips, this section is applicable. Contractor represents and warrants that it will provide only Four-Digit Date Compliant deliverables and services to the JBE. “Four-Digit Date Compliant” deliverables and services can accurately process, calculate, compare, and sequence date data, including date data arising out of or relating to leap years and changes in centuries. This warranty and representation is subject to the warranty terms and conditions of this Agreement and does not limit the generality of warranty obligations set forth elsewhere in this Agreement.

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:

  • Post-Commercial Operation Date Testing and Modifications Each Party shall at its own expense perform routine inspection and testing of its facilities and equipment in accordance with Good Utility Practice as may be necessary to ensure the continued interconnection of the Large Generating Facility with the Participating TO’s Transmission System in a safe and reliable manner. Each Party shall have the right, upon advance written notice, to require reasonable additional testing of the other Party’s facilities, at the requesting Party’s expense, as may be in accordance with Good Utility Practice.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!