Basis of Project Construction Sample Clauses

Basis of Project Construction. The Seller has obtained the use right of the State-owned land situated at the commercial and financial project under Phase II of Lugu Yinhe Business Zone by means of transfer. The State-owned Land Use Certificate Number of the Land is Jing-Shi-Xxx-Xxxx (2008) 0027, the space covered by the land use right is 34776.14m2, the land occupied by the commercial property (the “Property” hereinafter) purchased by the Buyer is for office use, and the land use period is from June 21, 2007 to June 20, 2057. The number of the State-owned Land Use Right Transfer Contract of the Land is Xxxx-Xx-Xxx [He] (2007) 0242, the land whereupon the Property is situated is for office use, and the term of the land use right transfer is from June 20, 2007 to June 19, 2057. The commercial property project constructed on the Land by the Seller as approved is temporarily named: Beijing Shijingshan Xxxxx Plaza (the “Project”), the construction project planning permit number is: 2007-Gui (Shi) Jian 0076, the construction permit number is: [2008] Shi-Jian 0022, the date of construction commencement and of completion agreed in the construction contract is January 15, 2008 and March 24, 2010 respectively.
Sample 1Sample 2
AutoNDA by SimpleDocs
Basis of Project Construction. 1.1 Site of Project Construction: A 00 Xxxxx Xxxxxxxxxxx Xxxx, Xxxxxxxx Xxxxxxxx, Xxxxxxx
Sample 1Sample 2
Basis of Project Construction. The Seller obtained the state-owned land use right of the plot at Fl. 10-11, Business Office Building, Lot 5, 05-13-10, 05-13-12, Gongchen Street, Fangshan District, by way of [transfer].
Sample 1
Basis of Project Construction. Party A signed No. 3202032010CR0023 Contract for the Assignment of the Use Right of State-owned Construction Land with the Bureau of Land and Resources of Wuxi City, Jiangsu Province of the People’s Republic of China. To acquire the land use right of lot No. 6-012-001-015 in Wuxi (Taihu) International Science and Technology Park TKY-GY-B-03(south of Gaolang Road and north of Guanshan Road) by means of transfer. The number of the Certificate of the Use of State-owned Land of the People’s Republic of China is Xixin State Use (2010) No. 1198. The land area of the land parcel is 106,960.5 square meters, and the land use is industrial land for research and development. The land use period is from February 12, 2010 to April 29, 2060. Party A has been approved to build industrial buildings for research and development on the above land parcel, named as Tian ‘an Smart City. The number of Construction Land Planning License is Jian Character No. 3202012010X0068, and the number of Construction Engineering Planning License is Jian Character No. 3202012010X0329. The number of Construction Project Planning Permit is 3202992011041900001A.
Sample 1
Basis of Project Construction. The bargainor, by the means of transfer , obtains the land-use right for the land plot numbering YT-3-2-1 that locates at Yxxx Xxxx Road, Xi’an The 【Number of Transfer Contract of Land-use Right】【Approval No. of Appropriation of Land-use Right】【Approval No. of Transfer of Appropriated Land-use Right】GF-92-1001 The land area of the plot is 3329.1 ㎡ , programmed purpose as dwelling the age limit from 2001/06/07 to 2065/10/22 (Y/M/D). The bargainor, at being approved, constructs commercial housing on the land plot mentioned above with the 【Present Name】【Temporary Name】 Millennium Star Mansion. The programming license of construction engineering is 221 , the number of license for construction is (2001) 0346 . _____________________________________________________________________________________________________
Sample 1

Related to Basis of Project Construction

  • Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and

  • Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)

  • Completion of Project The Project shall have been completed per the Plans and Specifications and a Completion Certificate shall have been obtained;

  • Legal Construction In the event that any one or more of the terms, provisions, or agreements that are contained in this Agreement shall be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable in any respect for any reason, the invalid, illegal, or unenforceable term, provision, or agreement shall not affect any other term, provision, or agreement that is contained in this Agreement and this Agreement shall be construed in all respects as if the invalid, illegal, or unenforceable term, provision, or agreement had never been contained herein.

  • Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Completion of Construction (a) For the purposes of this Agreement, the terms "

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • General Construction Principles Words in any gender are deemed to include the other genders. The singular is deemed to include the plural and vice versa. The headings and underlined paragraph titles are for guidance only and have no significance in the interpretation of this Agreement.

  • Strict Construction The parties to this Agreement have participated jointly in the negotiation and drafting of this Agreement. In the event an ambiguity or question of intent or interpretation arises, this Agreement will be construed as if drafted jointly by the parties, and no presumption or burden of proof will arise favoring or disfavoring any party by virtue of the authorship of any of the provisions of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!