COMPLAINTS HANDLING 44.1 Either Party shall notify the other Party of any Complaints made by Other Contracting Bodies, which are not resolved by operation of the Supplier's usual complaints handling procedure within five (5) Working Days of becoming aware of that Complaint and, if the Supplier is the Party providing the notice, such notice shall contain full details of the Supplier's plans to resolve such Complaint.
44.2 Without prejudice to any rights and remedies that a complainant may have at Law (including under this Framework Agreement and/or a Call Off Agreement), and without prejudice to any obligation of the Supplier to take remedial action under the provisions of this Framework Agreement and/or a Call Off Agreement, the Supplier shall use its all reasonable endeavours to resolve the Complaint within ten (10) Working Days and in so doing, shall deal with the Complaint fully, expeditiously and fairly.
44.3 Within two (2) Working Days of a request by the Authority, the Supplier shall provide full details of a Complaint to the Authority, including details of steps taken to achieve its resolution.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Claims Handling If a credible claim is made or threatened, for which Newegg is entitled to indemnification from Seller including without limitation the filing of a lawsuit against Newegg, or the receipt of a demand or notice by Newegg or Newegg elects to defend any claim for which Newegg is entitled to indemnification:
12.2.1. Newegg shall have the right to engage counsel of its choosing that Newegg deems, in its sole discretion, to be necessary for a competent defense of the suit;
12.2.2. Newegg shall pay all legal fees and expenses incurred in defense of the claim or suit as they become due. Seller shall reimburse Newegg for such fees and expenses within thirty (30) days from date of invoice or debit memo from Newegg. After thirty (30) days, Newegg will be entitled to deduct any unpaid invoice or debit memo amount from any amounts owed by Newegg to Seller. This shall not apply to any judgment or settlement amount, which amounts Newegg shall be entitled to notify, invoice or debit Seller's account at any time.
12.2.3. In the event a claim is made or a suit is filed directly against Newegg, and Newegg is defending such claim or suit, then Newegg, in its sole discretion, may settle the claim or suit. If Seller is defending the claim or suit, Seller may not settle the claim of suit absent the written consent of Newegg unless such settlement (i) includes a release of all claims pending against Newegg; (ii) contains no admission of liability or wrongdoing by Newegg; and (iii) imposes no obligations upon Newegg other than an obligation to stop selling any infringing items. Newegg agrees to provide reasonable assistance to Seller, at Seller's expense, regarding such claim or action.
DELIVERY, STORAGE, AND HANDLING The Contractor shall be responsible to inspect all components on delivery to ensure that no damage occurred during shipping or handling for furnish and installation projects. For equipment only purchases, the ordering entity shall be responsible to inspect all components on delivery. Materials must be stored in original undamaged packaging in such a manner to ensure proper ventilation and drainage, and to protect against damage, weather, vandalism, and theft until ready for installation.
Handling In order to protect such Confidential Information from improper disclosure, each Party agrees:
(a) That all Confidential Information shall be and shall remain the exclusive property of the source;
(b) To limit access to such Confidential Information to authorized employees who have a need to know the Confidential Information for performance of this Agreement;
(c) To keep such Confidential Information confidential and to use the same level of care to prevent disclosure or unauthorized use of the received Confidential Information as it exercises in protecting its own Confidential Information of a similar nature;
(d) Not to copy, publish, or disclose such Confidential Information to others or authorize anyone else to copy, publish, or disclose such Confidential Information to others without the prior written approval of the source;
(e) To return promptly any copies of such Confidential Information to the source at its request; and
(f) To use such Confidential Information only for purposes of fulfilling work or services performed hereunder and for other purposes only upon such terms as may be agreed upon between the Parties in writing.
Name Collision Report Handling 6.3.1 During the first two years after delegation of the TLD, Registry Operator’s emergency operations department shall be available to receive reports, relayed by ICANN, alleging demonstrably severe harm from collisions with overlapping use of the names outside of the authoritative DNS.
6.3.2 Registry Operator shall develop an internal process for handling in an expedited manner reports received pursuant to subsection 6.3.1 under which Registry Operator may, to the extent necessary and appropriate, remove a recently activated name from the TLD zone for a period of up to two years in order to allow the affected party to make changes to its systems.
Transportation Management Tenant shall fully comply with all present or future programs intended to manage parking, transportation or traffic in and around the Building, and in connection therewith, Tenant shall take responsible action for the transportation planning and management of all employees located at the Premises by working directly with Landlord, any governmental transportation management organization or any other transportation-related committees or entities.
Traffic Management 9.2.1 During the Operating Period, Developer shall be responsible for the general management of traffic on the Project. Developer shall manage traffic so as to preserve and protect safety of traffic on the Project and Related Transportation Facilities and, to the maximum extent practicable, to avoid disruption, interruption or other adverse effects on traffic flow, throughput or level of service on the Project and Related Transportation Facilities. Developer shall conduct traffic management in accordance with all applicable Technical Provisions, Technical Documents, Laws and Governmental Approvals, and in accordance with the Traffic Management Plan.
9.2.2 Developer shall prepare and submit to TxDOT and the Independent Engineer for TxDOT approval a Traffic Management Plan for managing traffic on the Project and Related Transportation Facilities after the commencement of traffic operations on any portion of the Project, addressing (a) orderly and safe movement and diversion of traffic on Related Transportation Facilities during Project construction, (b) orderly and safe movement of traffic on the Project and (c) orderly and safe diversion of traffic on the Project and Related Transportation Facilities necessary in connection with field maintenance and repair work or Renewal Work or in response to Incidents, Emergencies and lane closures. Developer shall prepare the Traffic Management Plan according to the schedule set forth in the Technical Provisions. The Traffic Management Plan shall comply with the Technical Provisions and Technical Documents concerning traffic management and traffic operations. Developer shall carry out all traffic management during the Term in accordance with the approved Traffic Management Plan.
9.2.3 Developer shall implement the Traffic Management Plan to promote safe and efficient operation of the Project and Related Transportation Facilities at all times during the course of any construction or operation of the Project and during the Utility Adjustment Work.
9.2.4 TxDOT shall have at all times, without obligation or liability to Developer, the right
9.2.4.1 Issue Directive Letters to Developer regarding traffic management
9.2.4.2 Provide on the Project, via message signs or other means consistent with Good Industry Practice, non-Discriminatory traveler and driver information, and other public information (e.g. amber alerts), provided that the means to disseminate such information does not materially interfere with the functioning of the ETCS.
Network Management 60.1 CLEC and CenturyLink will exchange appropriate information (e.g., network information, maintenance contact numbers, escalation procedures, and information required to comply with requirements of law enforcement and national security agencies) for network management purposes. In addition, the Parties will apply sound network management principles to alleviate or to prevent traffic congestion and to minimize fraud associated with third number billed calls, calling card calls, and other services related to this Agreement.
60.2 The Parties will employ characteristics and methods of operation that will not interfere with or impair the Parties’ networks, or the network of any third parties or Affiliated companies, connected with or involved directly in the network or facilities of CenturyLink.
60.3 CLEC shall not interfere with or impair service over any circuits, facilities or equipment of CenturyLink, its Affiliated companies, or its connecting and concurring carriers.
60.4 If CLEC causes any impairment or interference, CenturyLink shall promptly notify CLEC of the nature and location of the problem and that, unless promptly rectified, a temporary discontinuance of the use of any circuit, facility or equipment may be required. The Parties agree to work together to attempt to promptly resolve the impairment or interference. If CLEC is unable to promptly remedy, then CenturyLink may, at its option, temporarily discontinue the use of the affected circuit, facility or equipment until the impairment is remedied.
60.5 Any violation of Applicable Law or regulation regarding the invasion of privacy of any communications carried over CenturyLink’s facilities, or that creates hazards to the employees of CenturyLink or to the public, is also considered an impairment of service.
60.6 CenturyLink shall give advanced notice to CLEC of all non-scheduled maintenance or other planned network activities to be performed by CenturyLink on any Network Element, including any hardware, equipment, software, or system, providing service functionality of which CLEC has advised CenturyLink may potentially impact CLEC End Users.
60.7 The Parties shall provide notice of network changes and upgrades in accordance with 47 C.F.R. §§51.325 through 51.335. CenturyLink may discontinue any Interconnection arrangement, Telecommunications Service, or Network Element provided or required hereunder due to network changes or upgrades after providing CLEC notice as required by this Section. CenturyLink agrees to cooperate with CLEC and/or the appropriate regulatory body in any transition resulting from such discontinuation of service and to minimize the impact to customers which may result from such discontinuance of service.
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result.
38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center.
38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed.
38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties.
38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events.
38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time.
38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below.
38.7.1 AT&T TENNESSEE Disaster Recovery Plan
38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases.
38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate.
38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
