Build-Out Consistent with Specific Plan Sample Clauses

Build-Out Consistent with Specific Plan. As provided in the Special Planning District, the type, amount and density of land uses specified in the Specific Plan may be adjusted by relocating uses to adjoining or nearby parcels, except that surface parking granted by conditional use permit may not be relocated except as provided in the Special Conditions. Significant changes in the Development Plan may require subsequent environmental review. If LANDOWNER submits applications to CITY for Development that differs from the Development Plan, Specific Plan, Project Entitlements (including the Design Guidelines, Mitigation Measures, Tentative Map conditions, or Central Shops Historic District), or the Special Conditions and such applications do not require preparation of a subsequent or supplemental Subsequent Amended and Restated Railyards Development Agreement Revision Date: 10-21-2016 Environmental Impact Report or an amendment to this Agreement as referenced in Section 2.4.3, LANDOWNER’s Vested Rights under this Agreement will be adjusted to include the modifications upon approval of the application by CITY. Such adjustment in the Vested Rights shall be considered and implemented as a minor change under Section 2.4.4 of this Agreement. If an application proposes or requires a substantive change to the Development Plan, Specific Plan, Project Entitlements (including the Design Guidelines, Mitigation Measures, Tentative Map conditions, or Central Shops Historic District), the Special Conditions, or Land Use and Development Regulations under Section 2.4.3, then the right to develop the Property in accordance with the terms and conditions of that application, if approved, will not be vested under this Agreement unless and until this Agreement is amended to incorporate the approval pursuant to Section 2.4.3.
Sample 1
AutoNDA by SimpleDocs
Build-Out Consistent with Specific Plan. As provided in the Special Planning District, the type, amount and density of land uses specified in the Specific Plan may be adjusted by relocating uses to adjoining or nearby parcels. Significant changes in the Development Plan may require subsequent environmental review. To the extent that LANDOWNER submits applications to CITY for Development that differs from the Development Plan and such applications do not require preparation of a subsequent or supplemental environmental impact report or an amendment to this Agreement as referenced in Section 2.4.3, LANDOWNER’s Vested Rights under this Agreement will be adjusted to include the additional amount of Development and/or the Development Plan changes as authorized under a Subsequent Approval, as long as the application does not require an amendment to the Plans, Project Entitlements or Land Use and Development Regulations. Such adjustment in the Vested Rights shall be considered and implemented as a minor change under Section 2.4.4 of this Agreement. If an application requires an amendment to the Plans, Project Entitlements or Land Use and Development Regulations, CITY may require that this Agreement be amended in order to adjust the LANDOWNER’s Vested Rights accordingly. Railyards Development Agreement Revision Date: 12-05-07
Sample 1

Related to Build-Out Consistent with Specific Plan

  • Alignment with Modernization Foundational Programs and Foundational Capabilities The activities and services that the LPHA has agreed to deliver under this Program Element align with Foundational Programs and Foundational Capabilities and the public health accountability metrics (if applicable), as follows (see Oregon’s Public Health Modernization Manual, (xxxx://xxx.xxxxxx.xxx/oha/PH/ABOUT/TASKFORCE/Documents/public_health_modernization_man ual.pdf):

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

  • Provisioning of High Frequency Spectrum and Splitter Space 3.2.1 BellSouth will provide <<customer_name>> with access to the High Frequency Spectrum as follows:

  • Provisioning Line Splitting and Splitter Space 3.8.1 The Data LEC, Voice CLEC or BellSouth may provide the splitter. When EZ Phone or its authorized agent owns the splitter, Line Splitting requires the following: a non-designed analog Loop from the serving wire center to the NID at the End User’s location; a collocation cross connection connecting the Loop to the collocation space; a second collocation cross connection from the collocation space connected to a voice port; the high frequency spectrum line activation, and a splitter. The Loop and port cannot be a Loop and port combination (i.e. UNE-P), but must be individual stand-alone Network Elements. When BellSouth owns the splitter, Line Splitting requires the following: a non designed analog Loop from the serving wire center to the NID at the End User’s location with CFA and splitter port assignments, and a collocation cross connection from the collocation space connected to a voice port.

  • Escrow Format Specification 3.1. Deposit’s Format. Registry objects, such as domains, contacts, name servers, registrars, etc. will be compiled into a file constructed as described in draft-xxxxx-xxxxxxx-registry-data-escrow, see Part A, Section 9, reference 1 of this Specification and draft-xxxxx-xxxxxxx-dnrd-objects-mapping, see Part A, Section 9, reference 2 of this Specification (collectively, the “DNDE Specification”). The DNDE Specification describes some elements as optional; Registry Operator will include those elements in the Deposits if they are available. If not already an RFC, Registry Operator will use the most recent draft version of the DNDE Specification available at the Effective Date. Registry Operator may at its election use newer versions of the DNDE Specification after the Effective Date. Once the DNDE Specification is published as an RFC, Registry Operator will implement that version of the DNDE Specification, no later than one hundred eighty (180) calendar days after. UTF-8 character encoding will be used.

  • Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones:

  • Alternative Work Schedule An alternate forty (40) hour work schedule (other than five (5) uniform and consecutive eight (8) hour days in a seven (7) day period), or for hospital personnel an eighty (80) hour workweek in a fourteen (14) day period and other mutually agreed upon schedules that comply with applicable federal and state law. Employee work schedules normally include two (2) consecutive days off.

  • OGS Centralized Contract Modifications OGS, an Authorized User, or the Contractor may suggest modifications to the Centralized Contract or its Appendices. Except as specifically provided herein, modifications to the terms and conditions set forth herein may only be made with mutual written agreement of the Parties. Modifications may take the form of an update or an amendment. “

  • Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.

  • Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.

Time is Money Join Law Insider Premium to draft better contracts faster.