Construction Responsibilities The party named in Article 1, Responsible Parties, under AGREEMENT is responsible for the following:
A. Advertise for construction bids, issue bid proposals, receive and tabulate the bids, and award and administer the contract for construction of the Project. Administration of the contract includes the responsibility for construction engineering and for issuance of any change orders, supplemental agreements, amendments, or additional work orders that may become necessary subsequent to the award of the construction contract. Projects must be authorized by the State prior to advertising for construction.
B. If the State is the responsible party, the State will use its approved contract letting and award procedures to let and award the construction contract.
C. If the Local Government is the responsible party, the Local Government shall submit its contract letting and award procedures to the State for review and approval prior to letting.
D. If the Local Government is the responsible party, the State must concur with the low bidder selection before the Local Government can enter into a contract with the vendor.
E. If the Local Government is the responsible party, the State must review and approve change orders.
F. Upon completion of the Project, the party responsible for constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion and submit certification(s) sealed by a professional engineer(s) licensed in the State of Texas.
G. Upon completion of the Project, the party constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion.
Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.
Client’s Responsibilities In addition to other responsibilities herein or imposed by law, the Client shall:
(a) Designate in writing a person to act as its representative, such person having complete authority to transmit instructions, receive information, and make or interpret the Client's decisions.
(b) Provide all information and criteria as to the Client's requirements, objectives, and expectations for the project and all standards of development, design, or construction.
(c) Provide the Consultant all available studies, plans, or other documents pertaining to the project, such as surveys, engineering data, environmental information, etc., all of which the Consultant may rely upon.
(d) Arrange for access to the site and other property as required for the Consultant to provide its services.
(e) Review all documents or reports presented by the Consultant and communicate decisions pertaining thereto within a reasonable time so as not to delay the Consultant.
(f) Furnish approvals and permits from governmental authorities having jurisdiction over the project and approvals and consents from other parties as may be necessary.
(g) Obtain any independent accounting, legal, insurance, cost estimating and feasibility services required by Client.
(h) Give prompt written notice to the Consultant whenever the Client becomes aware of any development that affects the Consultant's services or any defect or noncompliance in any aspect of the project.
SCOPE OF WORK AND RESPONSIBILITIES 1. Interconnection Customer’s Scope of Work and Responsibilities
Client Responsibilities You are responsible for (a) assessing each participants’ suitability for the Training, (b) enrollment in the appropriate course(s) and (c) your participants’ attendance at scheduled courses.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Roles and Responsibilities 1. The Donor States shall make funds available in support of eligible programmes proposed by the Beneficiary State and agreed on by the Financial Mechanism Committee within the priority sectors listed in Article 3.1 of Protocol 38c and the programme areas listed in the Annex to Protocol 38c. The Donor States and the Beneficiary State shall cooperate on the preparation of concept notes defining the scope and planned results for each programme.
2. The Beneficiary State shall assure the full co-financing of programmes that benefit from support from the EEA Financial Mechanism 2014-2021 in accordance with Annex B and the programme agreements.
3. The Financial Mechanism Committee shall manage the EEA Financial Mechanism 2014-2021 and take decisions on the granting of financial assistance in accordance with the Regulation.
4. The Committee shall be assisted by the Financial Mechanism Office (hereinafter referred to as the “FMO”). The FMO shall be responsible for the day-to-day operations of the EEA Financial Mechanism 2014-2021 and shall serve as a contact point.
Management Responsibilities The exclusive representative recognizes the right and obligation of the School Board to efficiently manage and conduct the operation of the School District within its legal limitations and with its primary obligation to provide educational opportunity for the students of the School District.
Acknowledgement of Services and Responsibility of the Manager The Resident acknowledges that neither the Manager nor the Institution stands in loco parentis with respect to the Resident. The Residence provides living accommodations for independent students who are to be responsible and accountable for their personal needs and their interactions with their fellow residents as opposed to residential care. The Manager is responsible for the maintenance and operation of the residence. The Manager, in consultation with the Institution, may from time to time, in its sole and unfettered discretion, establish and/or amend policies, protocols and guidelines to uphold and ensure compliance with the standards set forth by the Manager, all of which will constitute part of the Residence Community Living Standards or Institution Code of Conduct, as appropriate. The Resident hereby acknowledges and agrees that they are solely responsible for their compliance with / review of such policies, protocols and guidelines (as may be created, amended, revised or restated by the Manager) found at xxx.xxxxxxxxxxxxxxxxx.xx.
Provider Responsibilities The Private Child-Caring Facility (PCC) (a.k.a., Provider) must comply with the following requirements: