Causes of Compensable Delay Sample Clauses

Causes of Compensable Delay a. If any of the following listed events results in delays to critical path activities and progress of the work which cumulatively have exceeded the Non-Compensable Delay Period and the Design-Builder has not caused a concurrent delay, such delays shall entitle the Design-Builder to compensation as provided in Section 10.03.3 Compensable Delays. (1) Delays caused by the Commission or the Commission Representative, as described in Section 10.03.1 above; (2) Acts of God, acts of the public enemy, fires, floods, earthquakes, epidemics, quarantine restrictions, labor strikes at the job site, or freight embargoes, provided that the listed causes were not foreseeable and did not result from the fault or negligence of the Design-Builder, and provided further that the Design-Builder has taken reasonable precautions to prevent further delays owing to such causes; (3) Acts (including delays in acting or failure to act) of the State, City or other governmental or regulatory authority, including, without limitation, restraining orders or injunctions requiring that the Work be stopped, delays in permit issuance or occupancy inspection, that are not the result of any fault or negligence of the Design-Builder or any of its Subcontractors; (4) Adverse weather delay days due to adverse weather conditions that when measured monthly are more than 25% more severe than the monthly averages for temperature or precipitation for Chicago (as determined by the National Oceanic & Atmospheric Administration), provided that actual adverse weather delays prevent work on critical path activities for more than 4 hours of a scheduled work day or cause a decrease in the field labor workforce hours on critical path activities of more than 70% on a scheduled work day; and (5) Delays resulting from subsurface or otherwise concealed conditions encountered at the project site which differ materially from those indicated in the contract documents as described in Section 3.04 Site Conditions and Inspection.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Causes of Compensable Delay a. If any of the following listed events results in delays to critical path activities and progress of the work which cumulatively have exceeded the Non-Compensable Delay Period and the Contractor has not caused a concurrent delay, such delays shall entitle the Contractor to compensation as provided in Section 10.03.3
Sample 1

Related to Causes of Compensable Delay

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.

  • Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.

  • Events Relating to Plans and Benefit Arrangements Any of the following occurs: (i) any Reportable Event, which the Agent determines in good faith constitutes grounds for the termination of any Plan by the PBGC or the appointment of a trustee to administer or liquidate any Plan, shall have occurred and be continuing; (ii) proceedings shall have been instituted or other action taken to terminate any Plan, or a termination notice shall have been filed with respect to any Plan; (iii) a trustee shall be appointed to administer or liquidate any Plan; (iv) the PBGC shall give notice of its intent to institute proceedings to terminate any Plan or Plans or to appoint a trustee to administer or liquidate any Plan; and, in the case of the occurrence of (i), (ii), (iii) or (iv) above, the Agent determines in good faith that the amount of the Borrower's liability is likely to exceed 10% of its Consolidated Tangible Net Worth; (v) the Borrower or any member of the ERISA Group shall fail to make any contributions when due to a Plan or a Multiemployer Plan; (vi) the Borrower or any other member of the ERISA Group shall make any amendment to a Plan with respect to which security is required under Section 307 of ERISA; (vii) the Borrower or any other member of the ERISA Group shall withdraw completely or partially from a Multiemployer Plan; (viii) the Borrower or any other member of the ERISA Group shall withdraw (or shall be deemed under Section 4062(e) of ERISA to withdraw) from a Multiple Employer Plan; or (ix) any applicable Law is adopted, changed or interpreted by any Official Body with respect to or otherwise affecting one or more Plans, Multiemployer Plans or Benefit Arrangements and, with respect to any of the events specified in (v), (vi), (vii), (viii) or (ix), the Agent determines in good faith that any such occurrence would be reasonably likely to materially and adversely affect the total enterprise represented by the Borrower and the other members of the ERISA Group;

  • Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.

  • WAIVER OF SPECIAL DAMAGES THE BORROWER WAIVES, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT THE UNDERSIGNED MAY HAVE TO CLAIM OR RECOVER FROM THE BANK IN ANY LEGAL ACTION OR PROCEEDING ANY SPECIAL, EXEMPLARY, PUNITIVE OR CONSEQUENTIAL DAMAGES.

  • Conditions to Receipt of Severance No Duty to Mitigate (a) Separation Agreement and Release of Claims. Executive will not receive severance pay or benefits other than the Accrued Obligations unless (x) Executive signs and does not revoke a separation agreement and release of claims in the form attached as Exhibit A, but with any appropriate reasonable modifications, reflecting changes in applicable law, as is necessary to provide the Company with the protection it would have if the Release was executed as of the date of this Agreement (the “Release”) and (y) such Release becomes effective and irrevocable no later than sixty (60) days following the termination date (such deadline, the “Release Deadline”). If the Release does not become effective and irrevocable by the Release Deadline, Executive will forfeit any rights to severance or benefits under this Agreement. All payments will be made upon the effectiveness of the Release but will be delayed until a subsequent calendar year if necessary so their timing does not result in penalty taxation under Section 409A. Severance payments or benefits will not be paid or provided until the Release becomes effective and irrevocable. For avoidance of doubt, although Executive’s severance payments and benefits are contractual rights, not “damages,” Executive is not required to seek other employment or otherwise “mitigate damages” as a condition of receiving such payments and benefits. (b) If any amount or benefit that would constitute non-exempt “deferred compensation” under Internal Revenue Code (“Code”) Section 409A would be payable under this Agreement by reason of Executive’s “separation from service” during a period in which Executive is a “specified employee” (within the meaning of Code Section 409A as determined by the Company), then any payment or benefits will be delayed until the earliest date on which they could be paid or distributed without being subject to penalty taxation under Code Section 409A. (c) Each payment and benefit payable under this Agreement is intended to constitute a separate payment under Treasury Regulations Section 1.409A-2(b)(2).

  • Waiver of Past Events of Servicing Termination The Holders of Notes evidencing not less than 51% of the Note Balance of the Controlling Class may, on behalf of all Noteholders, waive any Event of Servicing Termination and its consequences, except an event resulting from the failure to make any required deposits to or payments from the Collection Account, the Note Payment Account, the Certificate Payment Account or the Reserve Account in accordance with this Agreement. Upon any such waiver of an Event of Servicing Termination, such event shall cease to exist, and shall be deemed to have been remedied for every purpose of this Agreement. No such waiver shall extend to any subsequent or other event or impair any right arising therefrom, except to the extent expressly so waived.

  • Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!