CBSB Initiated Changes Sample Clauses

CBSB Initiated Changes. Before CBSB may amend or modify the scope or performance of this Agreement, the Project, the Master Production Record, the Project Scope, the Project Schedule and Budget or any other services provided in accordance with this Agreement, CBSB shall prepare a Change Order describing in reasonable detail the nature of such change(s), and propose such Change Order to Tercica for Tercica’s review and written approval. All approved Change Orders shall be signed by the Project Manager of each Party or by such other authorized representatives of CBSB and Tercica that the Project Managers may designate. If any changes contemplated by a Change Order will impact the estimated timing, estimated cost or scope of the Project, CBSB shall provide Tercica with a written description of such impacts in the Change Order. If Tercica approves the Change Order notwithstanding CBSB’s notice of any resulting cost increase, Tercica shall reimburse CBSB for the cost of such changes as detailed in the Change Order. Upon CBSB and Tercica’s approval of the Change Order, the Change Order will be implemented as soon as it is commercially practical to do so. For the avoidance of doubt, any changes to the parts of the CBSB Facility, utilities, equipment or processes used by CBSB in its performance of the Project, including those relating to the manufacturing, storage, testing, shipping and cleaning procedures that are used by CBSB in the manufacture of Drug Substance under this Agreement, shall require a Change Order prior to implementation of such change(s). For the further avoidance of doubt, [*] Project Rates during the Term of this Agreement.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to CBSB Initiated Changes

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.

  • Program Changes Contractor agrees to inform the County of any alteration in program or service delivery at least thirty (30) days prior to the implementation of the change, or as soon as reasonably feasible.

  • Implementation of Changes If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for completion of Landlord’s Work, if any, and (ii) deposits with Landlord any Excess TI Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by Tenant of any estimate of the delay caused by such proposed Change, the TI Architect’s determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant.

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.

  • Service Changes PBI may modify its Service by giving written notice to you (a “Service Change Notice”), which will state whether the change is material. After receiving a Service Change Notice, if the change is material, you may terminate Service by giving us a termination notice at the address indicated in Section 21 or you may create a case at xxxxxxxxxxx.xxx/xx/xxxxxxx-xx.xxxx (follow the instructions under “how to create a case”).

  • MINOR CHANGES IN THE WORK If permitted in the agreement between Owner and Architect, the Architect has authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents.

  • Material Changes Except as contemplated in the Prospectus, or disclosed in the Company’s reports filed with the Commission, there shall not have been any material adverse change in the authorized capital stock of the Company or any Material Adverse Effect or any development that would reasonably be expected to cause a Material Adverse Effect, or a downgrading in or withdrawal of the rating assigned to any of the Company’s securities (other than asset backed securities) by any rating organization or a public announcement by any rating organization that it has under surveillance or review its rating of any of the Company’s securities (other than asset backed securities), the effect of which, in the case of any such action by a rating organization described above, in the reasonable judgment of the Agent (without relieving the Company of any obligation or liability it may otherwise have), is so material as to make it impracticable or inadvisable to proceed with the offering of the Placement Shares on the terms and in the manner contemplated in the Prospectus.

  • Contractor Changes The Contractor shall notify DAS in writing no later than ten (10) Days from the effective date of any change in: a. its certificate of incorporation or other organizational document; b. more than a controlling interest in the ownership of the Contractor; or c. the individual(s) in charge of the Performance. This change shall not relieve the Contractor of any responsibility for the accuracy and completeness of the Performance. DAS, after receiving written notice by the Contractor of any such change, may require such agreements, releases and other instruments evidencing, to DAS’s satisfaction, that any individuals retiring or otherwise separating from the Contractor have been compensated in full or that provision has been made for compensation in full, for all work performed under terms of the Contract. The Contractor shall deliver such documents to DAS in accordance with the terms of DAS’s written request. DAS may also require, and the Contractor shall deliver, a financial statement showing that solvency of the Contractor is maintained. The death of any Contractor Party, as applicable, shall not release the Contractor from the obligation to Perform under the Contract; the surviving Contractor Parties, as appropriate, must continue to Perform under the Contract until Performance is fully completed.

  • Minor Changes Within Sale Area, minor adjustments may be made in boundaries of cutting units or in the timber individually Marked for cutting when ac- ceptable to Purchaser and Forest Service.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!