City-Caused Delay Sample Clauses

City-Caused Delay. 7.5.1 In the event a suspension, delay, interruption or failure to act of the City increases the cost of performance to any subcontractor, that subcontractor shall have the same rights against the Contractor for payment for an increase in the cost of his performance as the provisions 7.5.2 and 7.5.3 give the Contractor against the City, but nothing in provisions 7.5.2 and 7.5.3 shall in any way change, modify or alter any other rights which the Contractor or the subcontractor may have against each other. 7.5.2 The City may order the Contractor in writing to suspend, delay, or interrupt all or any part of the Work for such period of time as it may determine to be appropriate for the convenience of the City; provided however, that if there is a suspension, delay or interruption for fifteen (15) days or more or due to a failure of the City to act within the time specified in this Contract, the City shall make an adjustment in the Contract Price for any increase in the cost of performance of this Contract but shall not include any profit to the Contractor on such increase; and provided further, that the City shall not make any adjustment in the Contract Price under this provision for any suspension, delay, interruption or failure to act to the extent that such is due to any cause for which the Contract provides for an equitable adjustment of the Contract Price under any other Contract provisions. 7.5.3 The Contractor must submit the amount of a claim under provision 7.5.2 to the City in writing as soon as practicable after the end of the suspension, delay, interruption or failure to act and, in any event, not later than the date of final payment under this Contract and, except for costs due to a suspension order, the City shall not approve any costs in the claim incurred more than twenty
Sample 1
AutoNDA by SimpleDocs

Related to City-Caused Delay

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination as a Result of Death or Disability The Executive’s employment with the Company shall terminate automatically upon the Executive’s death during the Employment Term. If the Disability of the Executive has occurred during the Employment Term (pursuant to the definition of “Disability” set forth below), the Company may give to the Executive written notice of its intention to terminate the Executive’s employment. In such event, the Executive’s employment with the Company shall terminate effective on the 30th day after receipt of such notice by the Company (the “Disability Effective Date”), provided that, within the 30 days after receipt of notice, the Executive shall not have returned to substantial performance of the Executive’s duties. For purposes of this Agreement, “Disability” shall mean the absence of the Executive from the Executive’s duties with the Company for 120 consecutive days, or a total of 180 days in any 12-month period, as a result of incapacity due to mental or physical illness which is determined to be total and permanent by a physician jointly selected by the Company and the Executive or the Executive’s legal representative, or, if the parties cannot agree on the selection of such physician then each shall choose a physician and the two physicians shall jointly select a physician to make such binding determination.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Constructive Termination The Executive may terminate the Executive’s employment hereunder during the Change of Control Severance Period upon the occurrence of one or more of the following events (regardless of whether any other reason, other than Cause, for such termination exists or has occurred, including without limitation other employment), in which case the Executive shall be entitled to the benefits provided under Section 4(a) hereof: (i) failure to elect or reelect or otherwise to maintain the Executive in the office or the position, or a substantially equivalent office or position, which the Executive held immediately prior to the Change of Control; (ii) (A) a material adverse change in the nature or scope of the authorities, powers, functions, responsibilities or duties attached to the position that the Executive held immediately prior to the Change of Control; (B) a reduction in the Executive’s base salary from the rates in effect immediately prior to the Change of Control or a material modification in the scope of the Executive’s right to participate in any bonus program offered to similarly-situated employees; or (C) the termination or denial of the Executive’s rights to Benefits at least as great in the aggregate as are payable thereunder immediately prior to the Change of Control or a reduction in the scope or value thereof other than a general reduction applicable to all similarly-situated employees; (iii) a change in circumstances following the Change of Control, including, without limitation, a change in the scope of the business or other activities for which the Executive was responsible immediately prior to the Change of Control, which has rendered the Executive unable to carry out any material portion of the authorities, powers, functions, responsibilities or duties attached to the position held by the Executive immediately prior to the Change of Control, which situation is not remedied within 30 calendar days after written notice of such change given by the Executive; (iv) the liquidation, dissolution, merger, consolidation or reorganization of FTD or transfer of all or substantially all of its business and/or assets, unless the successor or successors (by liquidation, merger, consolidation, reorganization, transfer or otherwise) to which all or substantially all of its business and/or assets have been transferred (directly or by operation of law) shall have assumed all duties and obligations of FTD under this Agreement; or (v) the Executive is required to have his principal location of work changed to any location that is in excess of 50 miles from the Executive’s principal location of work immediately prior to the Change of Control. For purposes of this Agreement:

  • Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • EFFECTIVENESS; TERMINATION This Delegation Schedule shall be effective as of the date on which this Delegation Schedule shall have been accepted by the Delegate, as indicated by the date set forth below the Delegate's signature. This Delegation Schedule may be terminated at any time, without penalty, by written notice from the terminating party to the non-terminating party. Such termination shall be effective on the 30th calendar day following the date on which the non-terminating party shall receive the foregoing notice. The foregoing to the contrary notwithstanding, this Delegation Schedule shall be deemed to have been terminated concurrently with the termination of the Custodian Agreement.

  • Effective Term 1. The term of this Agreement shall be coterminous with the research period of the Collaborative Research. 2. The provisions of Article 21, Article 22, Article 28, and Article 29 shall survive the expiration of this Agreement.

  • Termination Due to Death or Disability The expiration of one (1) year from the date of the death of the Optionee or cessation of an Optionee’s employment or contractual relationship by reason of disability (as defined in Section 5.1(g) of the Plan). If an Optionee’s employment or contractual relationship is terminated by death, any Option held by the Optionee shall be exercisable only by the person or persons to whom such Optionee’s rights under such Option shall pass by the Optionee’s will or by the laws of descent and distribution.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!