City’s Obligations for Design, Construction, & Maintenance Sample Clauses

City’s Obligations for Design, Construction, & Maintenance. (a) City shall be responsible for designing, constructing, and maintaining the Improvements by managing and administering Contractor’s work under the Design-Build Contract. City shall be responsible for obtaining all applicable environmental and/or other clearances and permits and/or approvals necessary to complete the Improvements, subject to District’s reasonable cooperation to obtain all such permits and/or approvals. (b) City, upon District’s reasonable request, shall furnish to District all cost information, including any and all invoices and payments, related to the design, construction, and maintenance of the Improvements. (c) City shall provide District a reasonable opportunity to review and approve all design documents generated for the Improvements prior to approving such documents as set forth in the Design-Build Contract, and District’s approval(s) shall not be unreasonably withheld, conditioned, or delayed. (d) City shall require Contractor to obtain all required permits and approvals for all work related to the Improvements. (e) City, upon District’s reasonable request, shall provide District with as-built record drawings for the Improvements after acceptance of Improvements by City. (f) After City’s acceptance of the Improvements, City shall maintain all equipment in good working order and consistent with all requirements of the Financing Lease until the expiration or termination of the Financing Lease, or until title in the Equipment vests with District as set forth below, whichever occurs last.
Sample 1
AutoNDA by SimpleDocs

Related to City’s Obligations for Design, Construction, & Maintenance

  • Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.

  • Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.

  • Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-­‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.

  • Installation and Maintenance Except for the bi‐directional and production metering equipment owned by the City, all equipment on Customer’s side of the delivery point, including the required disconnect device, shall be provided and maintained in satisfactory operating condition by Customer and shall remain the property and responsibility of the Customer. The City will bear no responsibility for the installation or maintenance of Customer’s equipment or for any damage to property as a result of any failure or malfunction thereof. The City shall not be liable, directly or indirectly for permitting or continuing to allow the interconnection of the Facility or for the acts or omissions of Customer or the failure or malfunction of any equipment of Customer that causes loss or injury, including death, to any party.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Repairs and Maintenance It is the responsibility of the Tenant(s) to notify the Landlord immediately of any needed repair or unsafe condition existing around or in the Premises including but not limited to cracks in the foundation, cracks in plaster, moisture in walls and ceiling, buckling sheetrock or siding, or any leaks. If Xxxxxx(s) fails to immediately notify Landlord of visible problems, which result in damage to the unit, then Tenant(s) becomes liable for cost of resultant damage. All repairs necessary to maintain premises shall be done by or under the direction of the Landlord, at the Landlord’s expense, except those caused by negligence or acts of Tenant(s), Tenant’s agents, or invitees, which repairs shall be made at the sole cost of the Tenant(s). Such repairs shall be made to conform to the original condition of the Premises at the time the Tenant(s) took possession. Although the Landlord repairs normal wear and tear items, the adage “you broke it you pay to fix it” applies to the Tenant(s) and it applies during tenancy as well as at the end of tenancy. In addition, if a Tenant(s) calls for maintenance for which no such maintenance is needed (false call), Tenant(s) will be charged for the service call. Any repairs, including labor, material, and parts used, which are the responsibility of the Tenant(s), must be pre-approved in writing by the Landlord. Landlord shall be the sole judge as to what repairs are necessary. Landlord shall have no obligation to repair any defective condition, nor shall any defense or remedy be available to the Tenant(s), where the defective condition complained of was caused by the Tenant, Xxxxxx’s family, invitee, licensee, or other person acting under the control or direction of the Tenant(s), or where the Tenant unreasonably fails to notify the Landlord of the condition or allow the Landlord access to the Premises for purposes of the repair. Before exercising any of the remedies in accordance with the Landlord-Tenant Act, Tenant(s) must be current in rent. Tenant(s) shall be responsible for all broken glass. Tenant(s) shall not paint, re-wallpaper, or otherwise redecorate or make alterations to the Premises without the written consent of the Landlord. If written consent is given, such alterations shall be at the expense of the Tenant(s) and shall become part of the Premises and the Owner’s property upon termination of this Lease and tenancy. Tenant(s) shall not permit any act or thing deemed hazardous by Landlord due to potential risk of fire or which will increase the rate of insurance on said Premises. In case the Premises or surrounding areas shall be damaged by fire, rain, wind, or other cause beyond the control of the Landlord or the Tenant, then the Premises or surrounding areas shall be repaired within a reasonable time at the expense of the Landlord; and in case the damage is so extensive as to render the Premises unfit for human habitation, the rent shall cease until such time as the Premises will be put in repair. In case of total destruction, the rent shall be paid until the time of such destruction and from thenceforth this Lease Agreement shall cease and come to an end. In the event, the damage is caused by the act of the Tenant(s), or someone in or on the Premises by reason of Tenant’s permission or consent, there shall be no reduction of rent and Tenant(s) shall be liable for all costs of repair. Should Landlord notify Tenant(s) of intent to clean, replace carpets or paint the Premises, moving furniture and wall hangings shall be the duty and expense of the Tenant(s). Tenant(s) understands there will be no rent reductions, adjustments, or other compensation due to repairs or interruptions of service except as provided by law.

  • Operation and Maintenance 17.1 O&M obligations of the Concessionaire 17.1.1 During the Operation Period, the Concessionaire shall operate and maintain the Bus Terminal in accordance with this Agreement either by itself, or through the O&M Contractor and if required, modify, repair or otherwise make improvements to the Bus Terminal to comply with the provisions of this Agreement, Applicable Laws and Applicable Permits, and conform to Specifications and Standards and Good Industry Practice. The obligations of the Concessionaire hereunder shall include: (a) permitting safe, smooth and uninterrupted flow of traffic on the Bus Terminal during normal operating conditions. Buses of other state road transport corporations shall be parked inside the Bus Terminal for which no charges shall be payable to the Concessionaire and if any charges are applicable for such parking then it shall be realized by Authority only; (b) minimising incidents affecting the safety and use of the Bus Terminal by providing a rapid and effective response and maintaining liaison with emergency services of the State; (c) carrying out periodic preventive maintenance of the Bus Terminal; (d) undertaking routine maintenance including prompt repairs of ticket counters, Workshops, Authority's Office and other infrastructure as mentioned in the Operation and Maintenance Schedule; (e) undertaking major maintenance such as per the Maintenance Schedule of the major infrastructure in the Bus Terminal; (f) preventing, with the assistance of the concerned law enforcement agencies, any encroachments on the Bus Terminal; (g) protection of the environment and provision of equipment and materials therefor; (h) operation and maintenance of all communication, control and administrative systems necessary for the efficient operation of the Bus Terminal; (i) maintaining a public relations unit to interface with and attend to suggestions from the Users, passengers, government agencies, media and other agencies; (j) complying with Safety Requirements in accordance with Article 18; (k) operation and maintenance of all Project Assets diligently and efficiently and in accordance with Good Industry Practice; (l) maintaining punctuality and reliability in operating the Bus Terminal; and (m) maintaining a high standard of cleanliness and hygiene in the Bus Terminal. 17.1.2 The Concessionaire shall remove promptly from the Bus Terminal all surplus construction machinery and materials, waste materials (including hazardous materials and waste water), rubbish and other debris (including, without limitation, accident debris) and keep the Bus Terminal in a clean, tidy and orderly condition,

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Maintenance, Alteration and Repair (a) Resident is responsible for and agrees to take good care of the premises, fixtures and all common areas. Resident may not remove any of Owner’s property and will not perform any repairs, upgrades, painting, wallpapering, electric changes or other alterations of the premises without prior written consent from Owner. Resident will be responsible for damage from waste stoppages caused by foreign or improper objects or improper use in lines serving bathrooms, damage to fixtures, appliances, doors, windows, screens, damage from water faucets left on or from doors left open, and repairs or replacements to alarm devices necessitated by misuse or damage by Resident and/or guests. Extraordinary appliances or furnishings such as satellite dishes, hot tubs, pool tables, water beds or high utility-consuming devices may not be installed or placed on the premises or anywhere at the Property without Owner’s prior written consent, in its sole discretion. SAMPLE (b) In the case of a malfunction of any utilities or damage by fire, water or similar cause, or any water leak, suspected mold or microbial growth, electrical problem, broken glass, broken lock or any other condition that Resident reasonably believes poses a hazard to health and safety, Resident must promptly notify Owner in writing. Owner will act with reasonable time and diligence in making repairs and reconnections; Resident may not withhold or reduce payment of rent or other charges during such time. Maintenance and repair requested by Resident will generally be performed between 8am and 8pm, unless the work is considered an emergency, in which case work may take place at any time. Owner may temporarily disconnect equipment or utilities to avoid property damage and/or to perform repairs requiring such interruption, in Owner’s sole discretion. Owner will not be liable for any inconvenience, discomfort, disruption or interference with Resident use of the premises because of ongoing repairs, alterations or improvements to the Property or any apartment. (c) Following move-in, Resident is responsible for providing and changing all light bulbs and batteries (for smoke detectors and remote controls) in the assigned apartment. A written maintenance report requesting assistance in changing these items may be submitted for maintenance staff assistance, with extra charges payable by Resident as applicable per Owner’s published rates. From time to time, maintenance staff may enter the assigned apartment with or without notice to inspect and change furnace filters and to provide pest control.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!