Health, Safety and Security 22.2.1 The University and the Association agree to promote safe, secure and healthy working conditions and procedures, and to encourage Members to adopt and follow sound health, safety and security procedures in the performance of their work.
Pupil Safety and Fingerprinting CONTRACTOR shall comply with all provisions of the Education Code which protect the safety of any pupil that may come in contact with employees of the CONTRACTOR. Pursuant to Education Code section 45125.1, CONTRACTOR shall conduct criminal background checks of ALL employees of CONTRACTOR assigned to the PROJECT site, and shall certify that no employees who have been convicted of serious or violent felonies, as specified in Education Code Section 45125.1, will have contact with pupils, by utilizing the General Certification Regarding Background Checks Form. As part of such certification, CONTRACTOR must provide the District with a list of all employees providing services pursuant to this Agreement, and designate which sites such employees will be assigned. In performing the services set forth in this Agreement, CONTRACTOR shall not utilize any employees who are not included on the above-referenced list. At District’s sole discretion, District may make a finding, as authorized under Education Code section 45125.1, that CONTRACTOR’s employees will have only “limited contact” with pupils. In accordance with Education Code Section 45125.2, a CONTRACTOR performing construction, reconstruction, rehabilitation or repair services to a school facility shall not be required to perform Section 45125.1 background checks of all employees assigned to the PROJECT site if such CONTRACTOR installs a physical barrier at the worksite to limit employee contact with pupils and/or provides continual supervision and monitoring of all employees of the CONTRACTOR by an employee of the CONTRACTOR whom the Department of Justice has ascertained has not been convicted of a violent or serious felony. Such CONTRACTOR shall certify to the District its compliance with one of the aforementioned alternatives under Education Code Section 45125.2 pertaining to pupil safety with the form entitled CONSTRUCTION CONTRACTOR CERTIFICATION REGARDING BACKGROUND CHECKS which is on file at the Administrative Office of the DISTRICT. Contractor’s failure to comply with the law or Article VI, Paragraph 4 of this Agreement shall be considered a material breach of this Agreement upon where this Agreement may be terminated, at District’s sole discretion, without any further compensation to Contractor.
HEALTH, SAFETY AND ENVIRONMENT 41.1 In the performance of this Contract, Contractor and Operator shall conduct Petroleum Operations with due regard to health, safety and the protection of the environment (“HSE”) and the conservation of natural resources, and shall in particular:
Aviation safety (1) Each Contracting Party may request consultations at any time concerning the safety standards maintained by the other Contracting Party in areas relating to aeronautical facilities, flight crew, aircraft and the operation of aircraft. Such consultations shall take place within thirty (30) days of that request.
COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS The Contractor, it’s Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor’s obligations under this paragraph.
ENVIRONMENTAL PROTECTION STANDARDS CONTRACTOR shall be in compliance with the Clean Air Act (Title 42 USC Section 7401 et seq.), the Clean Water Act (Title 33 USC Section 1251 et seq.), Executive Order 11738 and Environmental Protection Agency, hereinafter referred to as “EPA,” regulations (Title 40 CFR), as any may now exist or be hereafter amended. Under these laws and regulations, CONTRACTOR assures that:
Federal Water Pollution Control Act 1. The contractor agrees to comply with all applicable standards, orders, or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 U.S.C. 1251 et seq.
National Environmental Policy Act All subrecipients must comply with the requirements of the National Environmental Policy Act (NEPA) 42 U.S.C. 4321 et seq., and the Council on Environmental Quality (CEQ) Regulations (40 C.F.R. Parts 1500-1508) for Implementing the Procedural Provisions of NEPA, which requires Subrecipients to use all practicable means within their authority, and consistent with other essential considerations of national policy, to create and maintain conditions under which people and nature can exist in productive harmony and fulfill the social, economic, and other needs of present and future generations of Americans.
Occupational Health and Safety Act The Employer, the Union and the employees agree to be bound by the provisions of the Occupational Health and Safety Act, S.N.S. 1996, c.7.
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
