COMMISSIONING PROGRAMME AND LIQUIDATED DAMAGES Sample Clauses

COMMISSIONING PROGRAMME AND LIQUIDATED DAMAGES. 4.1 Each party shall give written notice to the other declaring its readiness to commence the Commissioning Programme when this is the case. 4.2 The Commissioning Programme shall commence forthwith once both parties have given written notice to the other under Clause 4.1. 4.3 The Works shall be deemed to have been Commissioned on the date that the Independent Engineer certifies in writing to that effect. 4.4 In the event that the actual date of commencement of the Commissioning Programme is later than the Commissioning Programme Commencement Date The Company (if and to the extent that it is responsible for delayed commissioning beyond the Commissioning Programme Commencement Date, such responsibility and/or its extent to be determined by the Independent Engineer failing agreement between the parties) shall be liable to pay to the User Liquidated Damages for each day that the actual date of commencement of the Commissioning Programme is later than the Commissioning Programme Commencement Date. It is declared and agreed that such Liquidated Damages shall cease to be payable in respect of any period after the date of actual commencement of the Commissioning Programme. 4.5 In the event that the actual date on which the Construction Works are Commissioned is later than the Completion Date The Company (if and to the extent that it is responsible for delayed completion beyond the Completion Date, such responsibility and/or its extent to be determined by the Independent Engineer failing agreement between the parties) shall be liable to pay to the User Liquidated Damages for each day that the actual date on which the Construction Works are Commissioned is later than the Completion Date. It is hereby agreed and declared that such Liquidated Damages shall cease to be payable in respect of any period after completion of the Construction Works. 4.6 Liquidated Damages payable under Clauses 4.4 and 4.5 of this Construction Agreement shall accumulate on a daily basis but shall be payable calendar monthly. On or before the 15th day of each month the party entitled to receive the payment of Liquidated Damages shall send to the other party a statement of the Liquidated Damages which have accrued due in the previous calendar month. The party receiving such statement shall in the absence of manifest error pay the Liquidated Damages shown on the statement within 28 days of the date upon which the statement is received. 4.7 Without prejudice to and in addition to the obligation ...
AutoNDA by SimpleDocs

Related to COMMISSIONING PROGRAMME AND LIQUIDATED DAMAGES

  • CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is April 25, 2016. The completion date for this contract is October 15, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.

  • Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.

  • Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.

  • Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

  • Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

  • Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS. B. Such liquidated damages shall be calculated as an amount equaling the difference between: 1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and 2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract. C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.

  • Early and Safe Return to Work The Hospital and the Union are committed to a consistent, fair approach to meeting the needs of disabled workers, to restoring them to work which is meaningful for them and valuable to the Hospital, and to meeting the parties’ responsibilities under the law. To that end, the Hospital and the Union agree to cooperate in facilitating the return to work of disabled employees. The Employer and the Union agree that ongoing and timely communication by all participants in this process is essential to the success of the process. (a) At the regular HAC meeting or at least bi-monthly the Employer will provide an updated list of information to the bargaining unit president including the following: i) Nurses absent from work because of disability who are in receipt of Workplace Safety and Insurance Board benefits; ii) Nurses absent from work because of disability who are in receipt of Long Term Disability benefits including the last day worked; iii) Nurses who have been absent from work because of disability for more than twenty-four (24) months; iv) Nurses who are currently on a temporary modified work program; v) Nurses who are currently permanently accommodated in the workplace; vi) Nurses awaiting temporary modified work; vii) Nurses awaiting permanent accommodation in the workplace. (b) A disabled nurse returning to work from a disability including WSIB to a modified/light/alternative work program, will have a joint Return to Work Team (RTW) attend a return to work meeting. The RTW team will be comprised of the Bargaining Unit President or designate, the Occupational Health representative, the manager and Human Resources. If the Bargaining Unit President or designate attends RTW meetings on her day off, she / he will receive pay at straight time or time in lieu where possible for hours spent in RTW meetings. Such hours are invisible for the purposes of determining premium. L-2 The nurse will advise her manager and Occupational Health Services that she wishes to return to work. A disabled nurse who is ready to return to work will provide the Occupational Health Service with medical verification of her ability to return to work including information regarding any restrictions.

  • DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.

  • Public Posting of Approved Users’ Research Use Statement The PI agrees that information about themselves and the approved research use will be posted publicly on the dbGaP website. The information includes the PI’s name and Requester, project name, Research Use Statement, and a Non-Technical Summary of the Research Use Statement. In addition, and if applicable, this information may include the Cloud Computing Use Statement and name of the CSP or PCS. Citations of publications resulting from the use of controlled-access datasets obtained through this DAR may also be posted on the dbGaP website.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!