COMPENSATION EVENTS, RELIEF EVENTS AND FORCE MAJEURE Sample Clauses

COMPENSATION EVENTS, RELIEF EVENTS AND FORCE MAJEURE. 41COMPENSATION EVENTS If as a direct result of the occurrence of a Compensation Event: PPP Co. is unable to achieve Service Commencement on or before the Target Commencement Date; and/or PPP Co. is unable to comply with its obligations under this Project Agreement; and/or PPP Co. believes that it should be compensated for any Losses, it may have suffered or incurred; then PPP Co. is entitled to apply for an extension of the Target Completion Date and/or relief from its obligations and/or compensation under this Project Agreement. If PPP Co. claims relief or compensation or an extension of time under Clause 41.1 above, it must: as soon as practicable, and in any event within twenty-one (21) days of it becoming aware that the Compensation Event has caused or is likely to cause delay and/or breach of an obligation and/or Loss to PPP Co., give to the Authority a notice of its claim for an extension of the Target Completion Date, relief from its obligations, and/or payment of compensation and will provide sufficient details of the Compensation Event to enable the Authority to identify the nature and extent of the Compensation Event; and within fourteen (14) days after the notice referred to in Clause 41.2(a) (Compensation Events), give full details of the Compensation Event and the extension and/or any Estimated Increased Project Costs claimed and demonstrate to the reasonable satisfaction of the Authority that: the Compensation Event was the direct cause of the Estimated Increased Project Costs and/or any delay in the progress of the Works; and the Estimated Increased Project Costs, the time lost and/or breach of PPP Co.’s obligations could not reasonably be expected to be mitigated or recovered by PPP Co. acting in accordance with Good Industry Practice. Subject to PPP Co. complying with Clause 41.2 (Compensation Events) and such matters being agreed or otherwise being determined by the Dispute Resolution Procedure then: the Target Completion Date will be extended by such time as will be reasonable in respect of such a Compensation Event, taking into account the likely effect of delay; the Authority will not be entitled to exercise its rights in respect of the Compensation Event to terminate this Project Agreement under Clause 33 (Termination for PPP Co. Default); the Authority will give PPP Co. such relief from its obligations under this Project Agreement as is reasonable for such a Compensation Event; and the Authority will pay to PPP Co. an amount equal to...
Sample 1
AutoNDA by SimpleDocs

Related to COMPENSATION EVENTS, RELIEF EVENTS AND FORCE MAJEURE

  • Events of Force Majeure Neither Party shall be held liable or responsible to the other Party nor be deemed to be in default under, or in breach of any provision of, this Agreement for failure or delay in fulfilling or performing any obligation of this Agreement when such failure or delay is due to force majeure, and without the fault or negligence of the Party so failing or delaying. For purposes of this Agreement, force majeure is defined as causes beyond the control of the Party, including, without limitation, acts of God; acts, regulations, or laws of any government; war; civil commotion; destruction of production facilities or materials by fire, flood, earthquake, explosion or storm; labor disturbances; epidemic; and failure of public utilities or common carriers. In such event Medistem or Licensee, as the case may be, shall immediately notify the other Party of such inability and of the period for which such inability is expected to continue. The Party giving such notice shall thereupon be excused from such of its obligations under this Agreement as it is thereby disabled from performing for so long as it is so disabled and the 30 days thereafter. To the extent possible, each Party shall use reasonable efforts to minimize the duration of any force majeure.

  • Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.

  • Termination Events If the Early Termination Date results from a Termination Event:—

  • FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract. 19.2 If the Contractor is rendered unable, wholly or in part, by reason of force majeure to perform its obligations and meet its responsibilities under the Contract, UNDP shall have the right to suspend or terminate the Contract on the same terms and conditions as are provided for in Article 20, “Termination,” except that the period of notice shall be seven (7) days instead of thirty (30) days. In any case, UNDP shall be entitled to consider the Contractor permanently unable to perform its obligations under the Contract in case the Contractor is unable to perform its obligations, wholly or in part, by reason of force majeure for any period in excess of ninety (90) days. 19.3 Force majeure as used herein means any unforeseeable and irresistible act of nature, any act of war (whether declared or not), invasion, revolution, insurrection, terrorism, or any other acts of a similar nature or force, provided that such acts arise from causes beyond the control and without the fault or negligence of the Contractor. The Contractor acknowledges and agrees that, with respect to any obligations under the Contract that the Contractor must perform in areas in which UNDP is engaged in, preparing to engage in, or disengaging from any peacekeeping, humanitarian or similar operations, any delays or failure to perform such obligations arising from or relating to harsh conditions within such areas, or to any incidents of civil unrest occurring in such areas, shall not, in and of itself, constitute force majeure under the Contract.

  • Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.

  • Additional Disruption Events Change in Law: Applicable; provided that Section 12.9(a)(ii) of the Equity Definitions is hereby amended by adding the words “(including, for the avoidance of doubt and without limitation, adoption or promulgation of new regulations authorized or mandated by existing statute)” after the word “regulation” in the second line thereof.

  • Listing of Events of Default Each of the following events or occurrences described in this Section 8.1 shall constitute an "Event of Default".

  • Events of Default and Termination Events The following Events of Default and Termination Events shall apply to Party A and Party B as set forth below:

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.

  • Definition of Events of Default “Event of Default” means the occurrence of any of the following:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!